Search Legislation

Housing Grants, Construction and Regeneration Act 1996

Changes to legislation:

Housing Grants, Construction and Regeneration Act 1996 is up to date with all changes known to be in force on or before 07 October 2024. There are changes that may be brought into force at a future date. Help about Changes to Legislation

Close

Changes to Legislation

Revised legislation carried on this site may not be fully up to date. Changes and effects are recorded by our editorial team in lists which can be found in the ‘Changes to Legislation’ area. Where those effects have yet to be applied to the text of the legislation by the editorial team they are also listed alongside the affected provisions when you open the content using the Table of Contents below.

View outstanding changes

Changes and effects yet to be applied to :

  1. Introductory Text

  2. Part I Grants, &c. for renewal of private sector housing

    1. Chapter I The main grants

      1. Introductory

        1. 1. Grants for improvements and repairs, &c.

        2. 2. Applications for grants.

      2. Preliminary conditions

        1. 3.Ineligible applicants.

        2. 4. The age of the property.

        3. 5. Excluded descriptions of works.

        4. 6. Defective dwellings.

      3. Renovation grants

        1. 7. Renovation grants: owner’s applications and tenant’s applications.

        2. 8. Renovation grants: certificates required in case of owner’s application.

        3. 9. Renovation grants: certificates required in case of tenant’s application.

        4. 10. Renovation grants: prior qualifying period.

        5. 11. Prior qualifying period: the ownership or tenancy condition.

        6. 12. Renovation grants: purposes for which grant may be given.

        7. 13. Renovation grants: approval of application.

      4. Common parts grants

        1. 14. Common parts grants: occupation of flats by occupying tenants.

        2. 15. Common parts grants: landlord’s and tenants’ applications.

        3. 16. Common parts grants: certificate required to accompany application.

        4. 17. Common parts grants: purposes for which grant may be given.

        5. 18. Common parts grants: approval of application.

      5. Disabled facilities grants

        1. 19. Disabled facilities grants: owner’s and tenant’s applications.

        2. 20. Disabled facilities grants: the disabled occupant.

        3. 21. Disabled facilities grants: certificate required in case of owner’s application.

        4. 22. Disabled facilities grants: certificates required in case of tenant’s application.

        5. 22A.Certificates required in case of occupier’s application

        6. 23. Disabled facilities grants: purposes for which grant must or may be given.

        7. 24. Disabled facilities grants: approval of application.

      6. HMO grants

        1. 25. HMO grants: the interest of the applicant in the property.

        2. 26. HMO grants: certificate required to accompany application.

        3. 27. HMO grants: purposes for which grant may be given.

        4. 28. HMO grants: approval of application.

      7. Restrictions on grant aid

        1. 29. Restriction on grants for works already begun.

        2. 30. Means testing in case of application by owner-occupier or tenant.

        3. 31. Determination of amount of grant in case of landlord’s application.

        4. 32. Apportionment in case of tenants’ application for common parts grant.

        5. 33. Power to specify maximum amount of grant.

      8. Decision and notification

        1. 34. Decision and notification.

      9. Payment of grants

        1. 35. Payment of grants: general.

        2. 36. Delayed payment of mandatory grant.

        3. 37. Payment of grants: conditions as to carrying out of the works.

        4. 38. Payment of grants: conditions as to contractors employed.

        5. 39. Payment of grant to contractor.

        6. 40. Applicant ceasing to be entitled before payment of grant.

        7. 41. Change of circumstances affecting disabled occupant.

        8. 42. Cases in which grants may be re-calculated, withheld or repaid.

        9. 43. Repayment where applicant not entitled to grant.

      10. Grant conditions and repayment

        1. 44. Grant conditions: introductory.

        2. 45. Condition for repayment on disposal: renovation grants.

        3. 46. Condition for repayment on disposal: common parts grants.

        4. 47. Condition for repayment on disposal: HMO grants.

        5. 48. Condition as to owner-occupation: renovation grants.

        6. 49. Condition as to availability for letting: renovation grants.

        7. 50. Conditions as to occupation: HMO grants.

        8. 51. Conditions as to repayment in case of other compensation, &c.

        9. 52. Power to impose other conditions with consent of Secretary of State.

        10. 53. Meaning of relevant disposal.

        11. 54. Meaning of exempt disposal.

        12. 55. Cessation of conditions on repayment of grant, &c.

      11. Supplementary provisions

        1. 56. Provisions relating to death of applicant.

        2. 57. Power of local housing authority to carry out works which would attract grant.

        3. 58. Minor definitions: Chapter I.

        4. 59..

    2. Chapter II Group repair schemes

      1. Introductory

        1. 60. Group repair schemes.

        2. 61. Qualifying buildings.

        3. 62. Scheme works.

        4. 63. Approval of scheme by Secretary of State.

      2. Participation in group repair scheme

        1. 64. Persons eligible to participate in group repair scheme.

        2. 65. Scheme consent and restriction on works.

        3. 66. Certificate of completion date.

        4. 67. Contributions by participants.

      3. Variation of group repair scheme

        1. 68. Variation of group repair scheme.

      4. Conditions of participation

        1. 69. Conditions of participation: general.

        2. 70. Condition as to payment of balance of cost on disposal.

        3. 71. Conditions as to occupation.

        4. 72. Meaning of relevant disposal and exempt disposal.

        5. 73. Payment of balance of cost, &c: cessation of conditions.

      5. Supplementary provisions

        1. 74. Power of Secretary of State to modify operation of Chapter.

        2. 75. Index of defined expressions: Chapter II.

    3. Chapter III Home repair assistance

      1. 76. Home repair assistance.

      2. 77. Entitlement to home repair assistance.

      3. 78. Assistance in respect of house-boats and mobile homes.

      4. 79. Power to make further provision by regulations.

      5. 80. Index of defined expressions: Chapter III.

    4. Chapter IV Deferred action notices, &c.

      1. Deferred action notices

        1. 81. Deferred action notices.

        2. 82. Service of deferred action notices.

        3. 83. Appeals against deferred action notices.

        4. 84. Review of deferred action notices.

        5. 85. Guidance by Secretary of State.

      2. Power to improve enforcement procedures

        1. 86. Unfitness for human habitation &c.: power to improve enforcement procedures.

      3. Power to charge for enforcement action

        1. 87. Unfitness for human habitation, &c.: power to charge for enforcement action.

        2. 88. Recovery of charge for enforcement action.

      4. Supplementary provisions

        1. 89. Power to prescribe forms.

        2. 90. Minor definitions: Chapter IV.

        3. 91. Index of defined expressions: Chapter IV.

    5. Chapter V Supplementary provisions

      1. Contributions by Secretary of State

        1. 92. Contributions by the Secretary of State.

        2. 93. Recovery of contributions.

      2. Consent of the Secretary of State

        1. 94. Consent of the Secretary of State.

      3. Parsonages, charities, &c.

        1. 95. Parsonages, charities, &c.

      4. Interpretation

        1. 96. Meaning of “reasonable repair".

        2. 97. Fitness for human habitation.

        3. 98. Members of a person’s family and connected persons.

        4. 99. Meaning of “owner" of dwelling.

        5. 100. Disabled persons.

        6. 101. Minor definitions: Part I.

      5. Transitional and consequential provisions

        1. 102. Transitional provisions.

        2. 103. Consequential amendments: Part I.

  3. Part II Construction contracts

    1. Introductory provisions

      1. 104. Construction contracts.

      2. 105. Meaning of “construction operations".

      3. 106. Provisions not applicable to contract with residential occupier.

      4. 106A.Power to disapply provisions of this Part

      5. 107. Provisions applicable only to agreements in writing.

    2. Adjudication

      1. 108. Right to refer disputes to adjudication.

      2. 108A.Adjudication costs: effectiveness of provision

    3. Payment

      1. 109. Entitlement to stage payments.

      2. 110. Dates for payment.

      3. 110A.Payment notices: contractual requirements

      4. 110B.Payment notices: payee's notice in default of payer's notice

      5. 111. Requirement to pay notified sum.

      6. 112. Right to suspend performance for non-payment.

      7. 113. Prohibition of conditional payment provisions.

    4. Supplementary provisions

      1. 114. The Scheme for Construction Contracts.

      2. 115. Service of notices, &c.

      3. 116. Reckoning periods of time.

      4. 117. Crown application.

  4. Part III

    1. The Architects Registration Board

      1. 118. The Board and its committees.

      2. 119. Registrar and staff.

    2. Registration and discipline

      1. 120. Registration.

      2. 121. Discipline.

      3. 122. Code of practice.

    3. Miscellaneous

      1. 123. Offence of practising while not registered.

      2. 124. The Education Fund.

      3. 125. Supplementary.

  5. Part IV Grants &c. for regeneration, development and relocation

    1. Financial assistance for regeneration and development

      1. 126. Power of Secretary of State to give financial assistance for regeneration and development.

      2. 127. Regeneration and development: forms of assistance.

      3. 128. Regeneration and development: terms on which assistance is given.

      4. 129. Regeneration and development: consequential amendment.

      5. 130. Regeneration and development: Welsh Development Agency.

    2. Relocation grants in clearance areas

      1. 131. Resolution by local housing authority to pay relocation grants.

      2. 132. Relocation grants: applications and payments.

      3. 133. Relocation grants: qualifying persons and qualifying dwellings.

      4. 134. Relocation grants: amount.

      5. 135. Relocation grants: condition for repayment on disposal.

      6. 136. Relocation grants: conditions as to owner-occupation.

      7. 137. Relocation grants: cessation of conditions on repayment of grant, &c.

      8. 138. Relocation grants: liability to repay is a charge on dwelling.

      9. 139. Relocation grants: contributions by the Secretary of State.

      10. 140. Minor definitions relating to relocation grants.

  6. Part V Miscellaneous and general provisions

    1. Miscellaneous provisions

      1. 141. Existing housing grants: meaning of exempt disposal

      2. 142. Home energy efficiency schemes.

      3. 143. Urban development corporations: pre-dissolution transfers.

      4. 144. Housing action trusts: orders for dissolution.

      5. 145. The Commission for the New Towns: orders for dissolution.

    2. General provisions

      1. 146. Orders, regulations and directions.

      2. 147. Repeals and revocations.

      3. 148. Extent.

      4. 149. Corresponding provision for Northern Ireland.

      5. 150. Commencement.

      6. 151. Short title.

  7. SCHEDULES

    1. SCHEDULE 1

      Private sector renewal: consequential amendments

      1. Rent Act 1977 (c.42)

        1. 1.(1) Section 116 of the Rent Act 1977 (court order...

      2. Housing Act 1985 (c.68)

        1. 2.In section 47(4) of the Housing Act 1985 (limitation of...

        2. 3.In section 48(3A) of the Housing Act 1985 (information as...

        3. 4.(1) In section 100(2) of the Housing Act 1985 (power...

        4. 5.(1) In section 101(1) of the Housing Act 1985 (rent...

        5. 6.In section 190A of the Housing Act 1985 (repair notices...

        6. 7.(1) In section 244 of the Housing Act 1985 (environmental...

        7. 8.(1) In subsection (2)(b) of section 255 of the Housing...

        8. 9.In section 535(1)(a) of the Housing Act 1985 (exclusion of...

        9. 10.In section 605 of the Housing Act 1985 (consideration by...

      3. Landlord and Tenant Act 1985 (c.70)

        1. 11.(1) In subsection (1) of section 20A of the Landlord...

        2. 12.In section 21 of the Landlord and Tenant Act 1985...

      4. Housing Act 1988 (c.50)

        1. 13.In section 121(1) of the Housing Act 1988 (rent officers’...

      5. Local Government and Housing Act 1989 (c.42)

        1. 14.In section 93(5) of the Local Government and Housing Act...

        2. 15.(1) Section 169 of the Local Government and Housing Act...

    2. SCHEDULE 2

      1. Part I New First Schedule to the 1931 Act

        1. 1.This is the Schedule to be substituted for the First...

      2. Part II Other amendments

        1. The 1931 Act

          1. 2.(1) Section 2 of the 1931 Act (interpretation) is amended...

          2. 3.(1) Section 3 of the 1931 Act (constitution and functions...

          3. 4.(1) Section 6A of the 1931 Act (European qualifications) is...

          4. 5.(1) Section 7A of the 1931 Act (removal of name...

          5. 6.(1) Section 9 of the 1931 Act (right of appeal...

          6. 7.In section 11 of the 1931 Act (removal of name...

          7. 8.In section 12 of the 1931 Act (penalty for obtaining...

          8. 9.For section 13 of the 1931 Act (regulations) substitute— Rules....

          9. 10.(1) Section 15 of the 1931 Act (supply of regulations...

          10. 11.(1) Section 16 of the 1931 Act (service of documents)...

          11. 12.(1) Section 17 of the 1931 Act (defence for certain...

          12. 13.For section 18(2) of the 1931 Act (application to Northern...

        2. The 1938 Act

          1. 14.(1) Section 1A of the 1938 Act (visiting EC architects)...

          2. 15.In section 3 of the 1938 Act (offence of practising...

          3. 16.In section 5 of the 1938 Act (construction and citation),...

          4. 17.For section 6(1) of the 1938 Act (application to Northern...

        3. Other enactments

          1. 18.In section 6 of the Inspection of Churches Measure 1955...

          2. 19.In section 52(1) of the Cathedrals Measure 1963 (interpretation), in...

          3. 20.In section 20(1) of the Care of Cathedrals Measure 1990...

      3. Part III Transitional provisions and savings

        1. First elections and appointments to the Board

          1. 21.(1) Part I of the First Schedule to the 1931...

        2. Registration

          1. 22.Where before the appointed day a person has duly applied...

          2. 23.Examinations in architecture which immediately before the appointed day were...

          3. 24.Section 6B of the 1931 Act shall have effect as...

          4. 25.The first reference to the Board in section 7A(1) of...

        3. Discipline

          1. 26.Where before the appointed day— (a) the Discipline Committee has...

          2. 27.(1) Subject to sub-paragraph (2), the provisions substituted by section...

        4. Pre-commencement removals and disqualifications

          1. 28.(1) Where a person’s name has been removed from the...

          2. 29.A person may appeal under section 9 of the 1931...

          3. 30.Section 1A(6)(b) of the 1938 Act shall have effect as...

        5. Offence of practising while not registered

          1. 31.The amendments made in sections 1 and 3 of the...

          2. 32.The repeal made in section 3 of the 1938 Act...

        6. Transfer of Fund

          1. 33.If the transfer of the assets of the Fund takes...

        7. Supplementary

          1. 34.(1) In this Part of this Schedule—

          2. 35.Nothing in this Schedule prejudices the operation of section 16...

    3. SCHEDULE 3

      Repeals and Revocations

      1. Part I Grants, &c for renewal of private sector housing

      2. Part II Architects

      3. Part III Financial assistance for regeneration and development

Back to top

Options/Help

Print Options

You have chosen to open The Whole Act

The Whole Act you have selected contains over 200 provisions and might take some time to download. You may also experience some issues with your browser, such as an alert box that a script is taking a long time to run.

Would you like to continue?

You have chosen to open The Whole Act as a PDF

The Whole Act you have selected contains over 200 provisions and might take some time to download.

Would you like to continue?

You have chosen to open the Whole Act

The Whole Act you have selected contains over 200 provisions and might take some time to download. You may also experience some issues with your browser, such as an alert box that a script is taking a long time to run.

Would you like to continue?

Close

Legislation is available in different versions:

Latest Available (revised):The latest available updated version of the legislation incorporating changes made by subsequent legislation and applied by our editorial team. Changes we have not yet applied to the text, can be found in the ‘Changes to Legislation’ area.

Original (As Enacted or Made): The original version of the legislation as it stood when it was enacted or made. No changes have been applied to the text.

Close

Opening Options

Different options to open legislation in order to view more content on screen at once

Close

More Resources

Access essential accompanying documents and information for this legislation item from this tab. Dependent on the legislation item being viewed this may include:

  • the original print PDF of the as enacted version that was used for the print copy
  • lists of changes made by and/or affecting this legislation item
  • confers power and blanket amendment details
  • all formats of all associated documents
  • correction slips
  • links to related legislation and further information resources
Close

Timeline of Changes

This timeline shows the different points in time where a change occurred. The dates will coincide with the earliest date on which the change (e.g an insertion, a repeal or a substitution) that was applied came into force. The first date in the timeline will usually be the earliest date when the provision came into force. In some cases the first date is 01/02/1991 (or for Northern Ireland legislation 01/01/2006). This date is our basedate. No versions before this date are available. For further information see the Editorial Practice Guide and Glossary under Help.

Close

More Resources

Use this menu to access essential accompanying documents and information for this legislation item. Dependent on the legislation item being viewed this may include:

  • the original print PDF of the as enacted version that was used for the print copy
  • correction slips

Click 'View More' or select 'More Resources' tab for additional information including:

  • lists of changes made by and/or affecting this legislation item
  • confers power and blanket amendment details
  • all formats of all associated documents
  • links to related legislation and further information resources