The Triton Knoll Electrical System Order 2016

PART 6 Protection for electricity, gas and sewerage undertakers

1.  The provisions of this Part have effect for the protection of affected undertakers unless otherwise agreed in writing between the undertaker and the affected undertaker in question.

2.  In this Part—

“affected undertaker” means—

(a)

a licence holder within the meaning of Part 1 of the 1989 Act;

(b)

a gas transporter within the meaning of Part 1 of the Gas Act 1986(1);

(c)

a water undertaker(2); and

(d)

a sewerage undertaker,

for the area of the authorised development, and in relation to any apparatus, means the affected undertaker to whom it belongs or by whom it is maintained;

“alternative apparatus” means alternative apparatus adequate to enable the affected undertaker in question to fulfil its statutory functions in a manner no less efficient than previously;

“apparatus”—

(a)

in the case of an affected undertaker that is a licence holder within the meaning of Part 1 of the 1989 Act, means electric lines or electrical plant (as defined in the 1989 Act) belonging to or maintained by the affected undertaker;

(b)

in the case of an affected undertaker that is a gas transported within the meaning of Part 1 of the Gas Act 1986, means any mains, pipes or other apparatus belonging to or maintained by the affected undertaker for the purposes of gas supply;

(c)

in the case of an affected undertaker that is a water undertaker, means mains, pipes or other apparatus belonging to or maintained by the affected undertaker for the purposes of water supply; and

(d)

in the case of an affected undertaker that is a sewerage undertaker—

(i)

means—

(aa)

any drain or works vested in the affected undertaker under the Water Industry Act 1991; and

(bb)

any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) of that Act or an agreement to adopt made under section 104 of that Act; and

(ii)

includes a sludge main, disposal main (within the meaning of section 219 of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works,

and in each case includes any structure in which apparatus is or will be lodged or which gives or will give access to apparatus;

“functions” includes powers and duties;

“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over or on land.

3.  This Part does not apply to apparatus in respect of which the relations between the undertaker and the affected undertaker are regulated by Part 3 of the 1991 Act (street works in England and Wales).

4.  Despite any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.

5.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed, the apparatus must not be removed under this Part, and any right of an affected undertaker to maintain that apparatus in the land must not be extinguished until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of the affected undertaker in question.

(2) If, for the purpose of executing any works in, on or under any land purchased, held or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to the affected undertaker in question written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed; and in that case (or if in consequence of the exercise of any of the powers conferred by this Order an affected undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to the affected undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford the facilities and rights referred to in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed, the affected undertaker in question must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably practicable use all reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

(4) Any alternative apparatus to be constructed in land of the undertaker under this Part must be constructed in such manner and in such line or situation as may be agreed between the affected undertaker in question and the undertaker or in default of agreement settled by arbitration in accordance with article 36 (arbitration).

(5) The affected undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 36, and after the grant to the affected undertaker of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under this Part.

(6) Despite anything in sub-paragraph (5), if the undertaker gives notice in writing to the affected undertaker in question that it desires itself to execute any work, or part of any work in connection with the construction or removal of apparatus in any land controlled by the undertaker, that work, instead of being executed by the affected undertaker, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the affected undertaker .

(7) Nothing in sub-paragraph (6) authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus.

6.—(1) Where, in accordance with this Part, the undertaker affords to an affected undertaker facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted on such terms and conditions as may be agreed between the undertaker and the affected undertaker in question or in default of agreement settled by arbitration in accordance with article 36.

(2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the affected undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to the affected undertaker as appears to the arbitrator to be reasonable, having regard to all the circumstances of the particular case.

7.—(1) Not less than 28 days before commencing the execution of any works of the type referred to in paragraph 5(2) that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under that sub-paragraph, the undertaker must submit to the affected undertaker in question a plan, section and description of the works to be executed.

(2) The works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the affected undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it; and the affected undertaker is entitled to watch and inspect the execution of the works.

(3) Any requirements made by an affected undertaker under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.

(4) If an affected undertaker, in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 5 and 6 apply as if the removal of the apparatus had been required by the undertaker under paragraph 5(2).

(5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and the undertaker having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

(6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency, but in that case it must give to the affected undertaker in question notice as soon as is reasonably practicable and a plan, section and description of the works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

8.—(1) Subject to the following provisions of this paragraph, the undertaker must repay to an affected undertaker the reasonable expenses incurred by the affected undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus (including costs or compensation payable in connection with the acquisition of land for that purpose) which may be required in consequence of the execution of any works referred to in paragraph 5(2).

(2) The value of any apparatus removed under this Part, that value being calculated after removal, must be deducted from any sum payable under sub-paragraph (1).

(3) If in accordance with this Part—

(a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 36 to be necessary, then, if such placing involves cost in the construction of works under this Part exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the affected undertaker in question by virtue of sub-paragraph (1) must be reduced by the amount of that excess.

(4) For the purposes of sub-paragraph (3)—

(a) an extension of apparatus to a length greater than the length of existing apparatus must not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b) where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole must be treated as if it also had been agreed or had been so determined.

(5) An amount which, apart from this sub-paragraph, would be payable to an affected undertaker in respect of works by virtue of sub-paragraph (1) must, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the affected undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

9.—(1) Subject to sub-paragraphs (2) and (3), if, by reason or in consequence of the construction of any works referred to in paragraph 5(2), any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the works) or property of an affected undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any affected undertaker, the undertaker must—

(a) bear and pay the cost reasonably incurred by the affected undertaker in making good the damage or restoring the service or supply; and

(b) make reasonable compensation to the affected undertaker for any other expenses, loss, damages, penalty or costs incurred by the affected undertaker by reason or in consequence of the damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an affected undertaker, its officers, servants, contractors or agents.

(3) An affected undertaker must give the undertaker reasonable notice of any claim or demand, and no settlement or compromise may be made without the consent of the undertaker which, if it withholds consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

10.  Nothing in this Part affects the provisions of any enactment or agreement regulating the relations between the undertaker and an affected undertaker in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

(1)

1986 c.44

(2)

“Water undertaker” is defined in Schedule 1 to the Interpretation Act 1978.