Search Legislation

Advanced Search

New Roads and Street Works Act 1991

Help about what version

What Version

Help about advanced features

Advanced Features

Changes over time for: Part III

Help about opening options

Alternative versions:

Changes to legislation:

New Roads and Street Works Act 1991, Part III is up to date with all changes known to be in force on or before 13 October 2026. There are changes that may be brought into force at a future date. Changes that have been made appear in the content and are referenced with annotations. Help about Changes to Legislation

Close

Changes to Legislation

Revised legislation carried on this site may not be fully up to date. Changes and effects are recorded by our editorial team in lists which can be found in the ‘Changes to Legislation’ area. Where those effects have yet to be applied to the text of the legislation by the editorial team they are also listed alongside the legislation in the affected provisions. Use the ‘more’ link to open the changes and effects relevant to the provision you are viewing.

View outstanding changes

Changes and effects yet to be applied to Part III:

Changes and effects yet to be applied to the whole Act associated Parts and Chapters:

Whole provisions yet to be inserted into this Act (including any effects on those provisions):

Part IIIU.K. Street works in England and Wales

Modifications etc. (not altering text)

C2Pt. 3 (ss. 48-106) applied (6.11.2000) by 2000 c. 26, s. 95, Sch. 6 para. 1(3); S.I. 2000/2957, art. 2(1), Sch. 1

Pt. 3 (ss. 48-106) modified (29.3.2001) by S.I. 2001/1348, art. 21(2)

Pt. 3 (ss. 48-106) amended (24.7.2001) by S.I. 2001/3627, art. 4(1)

C3Definition in Pt. 3 (ss. 48-106) applied (1.12.1991) by Water Industry Act 1991 (c. 56, SIF 130), ss. 71-84, 162-172, 219(1), 223(2), Sch. 6 para. 6(3)(a).

C4Definition in Pt. 3 (ss. 48-106) applied (1.12.1991) by Water Resources Act 1991 (c. 57, SIF 130), ss. 178, 221(1), 225(2), Sch. 22 para. 3(2).

C5Pt. 3 excluded (16.3.1992) by Avon Weir Act 1992 (c. v), s. 6(3) (with s. 61(1))

C6Pt. 3 modified (1.1.1993) by Pipelines Act 1962 (c. 58), s. 16(1) (as substituted (1.1.1993) by New Roads and Street Works Act 1991 (c. 22), s. 168(1), Sch. 8 Pt. 3 para. 101(3); S.I. 1992/2984, art. 2(2), Sch.2)

Pt. 3 modified (27.7.1993) by 1993 c. xv, s. 4(1)

Pt. 3 (ss. 48-106) excluded (27.7.1993) by 1993 c. xv, s. 4(2)

C7Pt. 3 applied (with modifications) (21.7.1994) by 1994 c. xv, s. 4(1)

Pt. 3 applied (21.7.1994) by 1994 c. xv, s. 45(5)(a)

Pt. 3 excluded (21.7.1994) by 1994 c. xv, s. 21(2)

Pt. 3 restricted (21.7.1994) by 1994 c. xv, s. 4(2)

C8Pt. 3 excluded (18.12.1996) by 1996 c. 61, s. 52, Sch. 15 para. 1(3)

Pt. 3 modified (18.12.1996) by 1996 c. 61, s. 3, Sch. 3 para. 8

C9Pt. 3 extended (28.7.1998) by 1998 c. iv, s. 3

C10Pt. 3 applied (27.8.1998) by S.I. 1998/1936, arts. 1, 41, Sch. 10 paras. 2(8), 3(2)

Pt. 3 modified (13.1.1999) by S.I. 1998/3269, art. 4(1)

C26Pt. 3 modified (22.7.2008) by Crossrail Act 2008 (c. 18), Sch. 3 para. 8

C27Pt. 3 excluded (22.7.2008) by Crossrail Act 2008 (c. 18), Sch. 17 para. 1(3)

C34Pt. 3 applied (with modifications) (9.4.2013) by The Hinkley Point C (Nuclear Generating Station) Order 2013 (S.I. 2013/648), arts. 1, 9 (with arts. 48, 68, 79)

C37Pt. 3 modified (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(1)(2)

C64Pt. 3 applied (with modifications) (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(2) (with arts. 55-57, Sch. 8 para. 13)

C89Pt. 3 modified (6.6.2022) by The M25 Junction 28 Development Consent Order 2022 (S.I. 2022/573), arts. 1, 10(1)(2) (with arts. 5, 36) (as amended (7.2.2024) by S.I. 2024/129, art. 1, Sch.)

C119Pt. 3 modified (25.2.2026) by The A46 Coventry Junctions (Walsgrave) Development Consent Order 2026 (S.I. 2026/125), arts. 1, 10(1) (with arts. 40, 45, Sch. 9) (which affecting provisions were superseded by S.I. 2026/537, arts. 1, 10(1) (with arts. 40, 45, Sch. 9))

Introductory provisionsE+W

48 Streets, street works and undertakers.E+W

(1)In this Part a “street” means the whole or any part of any of the following, irrespective of whether it is a thoroughfare—

(a)any highway, road, lane, footway, alley or passage,

(b)any square or court, and

(c)any land laid out as a way whether it is for the time being formed as a way or not.

Where a street passes over a bridge or through a tunnel, references in this Part to the street include that bridge or tunnel.

(2)The provisions of this Part apply to a street which is not a maintainable highway subject to such exceptions and adaptations as may be prescribed.

(3)In this Part “street works” means works of any of the following kinds (other than works for road purposes) executed in a street in pursuance of a statutory right or a street works licence—

(a)placing apparatus, or

(b)inspecting, maintaining, adjusting, repairing, altering or renewing apparatus, changing the position of apparatus or removing it,

or works required for or incidental to any such works (including, in particular, breaking up or opening the street, or any sewer, drain or tunnel under it, or tunnelling or boring under the street).

[F1(3ZA)In this Part “street works” also includes works of any of the following kinds executed in a street in England in pursuance of a street works permit—

(a)placing apparatus that is a public charge point, or

(b)inspecting, maintaining, adjusting, repairing, altering, renewing, changing the position of or removing apparatus that is a public charge point,

or works required for or incidental to any such works (including, in particular, breaking up or opening the street, or any sewer, drain or tunnel under it, or tunnelling or boring under the street).]

[F2(3A)For the purposes of subsection (3) [F3or (3ZA)], the works that are street works by virtue of being works required for or incidental to street works of any particular kind include—

(a)reinstatement of the street, and

(b)where an undertaker has failed to comply with his duties under this Part with respect to reinstatement of the street, any remedial works.]

(4)In this Part “undertaker” [F4—

(a)in relation to street works mentioned in subsection (3),] means the person by whom the relevant statutory right is exercisable (in the capacity in which it is exercisable by him) or the licensee under the relevant street works licence, as the case may be;

[F5(b)in relation to street works described in subsection (3ZA), means the person who in accordance with the street works permit is permitted to carry out the works.]

(5)References in this Part to the undertaker in relation to apparatus in a street [F6(including public charge points) are to the person entitled, by virtue of—

(a)a statutory right,

(b)a street works licence, or

(c)where the apparatus is a public charge point installed in England in pursuance of a street works permit, the permit,]

to carry out in relation to the apparatus such works as are mentioned in subsection (3) [F7or (3ZA)]; and references to an undertaker having apparatus in the street, or to the undertaker to whom apparatus belongs, shall be construed accordingly.

Textual Amendments

Modifications etc. (not altering text)

C144S. 48(3) modified (11.10.2023) by The Awel y Môr Offshore Wind Farm Order 2023 (S.I. 2023/1033), arts. 1, 9(2) (with arts. 36, 37, Sch. 9 paras. 14, 44(1), 76, 103)

C153S. 48(3) modified (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(2) (with Sch. 15)

C154S. 48(3) modified (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(2) (with art. 44, Sch. 12)

C156S. 48(3) modified (27.9.2024) by The Cottam Solar Project Order 2024 (S.I. 2024/943), arts. 1, 8(2) (with art. 48, Sch. 15)

C166S. 48(3) modified (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(2) (with Sch. 10)

C171S. 48(3) modified (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(2) (with art. 49, Sch. 15)

C176S. 48(3) modified (25.2.2026) by The A46 Coventry Junctions (Walsgrave) Development Consent Order 2026 (S.I. 2026/125), arts. 1, 11(2) (with arts. 40, 45, Sch. 9) (which affecting provisions were superseded by S.I. 2026/537, arts. 1, 11(2) (with arts. 40, 45, Sch. 9))

C178S. 48(3) modified (11.3.2026) by The Fenwick Solar Farm Order 2026 (S.I. 2026/151), arts. 1, 8(2) (with Sch. 14)

49 The street authority and other relevant authorities.E+W

(1)In this Part “the street authority” in relation to a street means, subject to the following provisions—

(a)if the street is a maintainable highway, the highway authority, and

(b)if the street is not a maintainable highway, the street managers.

(2)In the case of a highway for which the Secretary of State [F8or a strategic highways company] is the highway authority but in relation to which a local highway authority acts as his [F9or its] agent under section 6 of the M1Highways Act 1980, the local highway authority shall be regarded as the street authority for the purposes of section 53 (the street works register) and sections 54 to 60 (advance notice and co-ordination of works).

(3)Subsection (1)(b) has effect subject to section 87 as regards the application of this Part to prospectively maintainable highways.

(4)In this Part the expression “street managers”, used in relation to a street which is not a maintainable highway, means the authority, body or person liable to the public to maintain or repair the street or, if there is none, any authority, body or person having the management or control of the street.

(5)The Secretary of State may by regulations make provision for exempting street managers from provisions of this Part which would otherwise apply to them as the street authority in relation to a street.

(6)References in this Part to the relevant authorities in relation to any works in a street are to the street authority and also—

(a)where the works include the breaking up or opening of a public sewer in the street, the sewer authority;

(b)where the street is carried or crossed by a bridge vested in a transport authority, or crosses or is crossed by any other property held or used for the purposes of a transport authority, that authority; and

(c)where in any other case the street is carried or crossed by a bridge, the bridge authority.

Textual Amendments

Marginal Citations

50 Street works licences.E+W

(1)The street authority may grant a licence (a “street works licence”) permitting a person—

(a)to place, or to retain, apparatus in the street, and

(b)thereafter to inspect, maintain, adjust, repair, alter or renew the apparatus, change its position or remove it,

and to execute for those purposes any works required for or incidental to such works (including, in particular, breaking up or opening the street, or any sewer, drain or tunnel under it, or tunnelling or boring under the street).

[F10(1A)For the purposes of subsection (1), the works that are required for or incidental to works falling within paragraph (a) or (b) of that subsection include—

(a)reinstatement of the street, and

(b)where an undertaker has failed to comply with his duties under this Part with respect to reinstatement of the street, any remedial works.]

(2)A street works licence authorises the licensee to execute the works permitted by the licence without obtaining any consent which would otherwise be required to be given—

(a)by any other relevant authority in its capacity as such, or

(b)by any person in his capacity as the owner of apparatus affected by the works;

but without prejudice to the provisions of this Part as to the making of requirements by any such authority or person or as to the settlement of a plan and section and the execution of the works in accordance with them.

(3)A street works licence does not dispense the licensee from obtaining any other consent, licence or permission which may be required; and it does not authorise the installation of apparatus for the use of which the licence of the Secretary of State is required, unless and until that licence has been granted.

(4)The provisions of Schedule 3 have effect with respect to the grant of street works licences, the attachment of conditions and other matters.

(5)A street works licence may be granted—

(a)to a person on terms permitting or prohibiting its assignment, or

(b)to the owner of land and his successors in title;

and references in this Part to the licensee are to the person for the time being entitled by virtue of the licence to do anything permitted by it.

(6)Any licence, consent, permission or other authority for the execution in a street of any such works as are mentioned in subsection (1) granted or given by the street authority before the commencement of this Part has effect after the commencement of this Part as a street works licence; but subsection (2) does not apply in relation to such a licence.

This applies in particular to licences granted under section 181 of the M2Highways Act 1980 or any corresponding earlier enactment.

(7)The works referred to in subsection (1) above do not include works for road purposes.

Textual Amendments

Modifications etc. (not altering text)

C186S. 50: functions of local authority not to be responsibility of an executive of the authority (E.) (16.11.2000) by virtue of S.I. 2000/2853, reg. 2(1), Sch. 1 Table B41

Marginal Citations

51 Prohibition of unauthorised street works.E+W

(1)It is an offence for a person other than the street authority—

(a)to place apparatus in a street, or

(b)to break up or open a street, or a sewer, drain or tunnel under it, or to tunnel or bore under a street, for the purpose of placing, inspecting, maintaining, adjusting, repairing, altering or renewing apparatus, or of changing the position of apparatus or removing it,

otherwise than in pursuance of a statutory right or a street works licence.

(2)A person committing an offence under this section is liable on summary conviction to a fine not exceeding [F11level 5] on the standard scale.

(3)This section does not apply to [F12—

(a)works for road purposes,

(b)emergency works of any description, or

(c)street works as described in section 48(3ZA) (works relating to public charge points executed in a street in England in pursuance of a street works permit).]

(4)If a person commits an offence under this section, the street authority may—

(a)in the case of an offence under subsection (1)(a), direct him to remove the apparatus in respect of which the offence was committed, and

(b)in any case, direct him to take such steps as appear to them necessary to reinstate the street or any sewer, drain or tunnel under it.

If he fails to comply with the direction, the authority may remove the apparatus or, as the case may be, carry out the necessary works and recover from him the costs reasonably incurred by them in doing so.

Textual Amendments

F11Words in s. 51(2) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

F12Words in s. 51(3) substituted (13.3.2026) by Planning and Infrastructure Act 2025 (c. 34), ss. 49(6), 118(1)(z5) (with s. 116); S.I. 2026/292, reg. 2

Modifications etc. (not altering text)

C206S. 51(1) modified (11.10.2023) by The Awel y Môr Offshore Wind Farm Order 2023 (S.I. 2023/1033), arts. 1, 9(2) (with arts. 36, 37, Sch. 9 paras. 14, 44(1), 76, 103)

C216S. 51(1) modified (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(2) (with art. 44, Sch. 12)

C217S. 51(1) modified (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(2) (with Sch. 15)

C218S. 51(1) modified (27.9.2024) by The Cottam Solar Project Order 2024 (S.I. 2024/943), arts. 1, 8(2) (with art. 48, Sch. 15)

C227S. 51(1) modified (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(2) (with Sch. 10)

C232S. 51(1) modified (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(2) (with art. 49, Sch. 15)

C237S. 51(1) modified (25.2.2026) by The A46 Coventry Junctions (Walsgrave) Development Consent Order 2026 (S.I. 2026/125), arts. 1, 11(2) (with arts. 40, 45, Sch. 9) (which affecting provisions were superseded by S.I. 2026/537, arts. 1, 11(2) (with arts. 40, 45, Sch. 9))

C239S. 51(1) modified (11.3.2026) by The Fenwick Solar Farm Order 2026 (S.I. 2026/151), arts. 1, 8(2) (with Sch. 14)

F1352 Emergency works.E+W

(1)In this Part “emergency works” means works whose execution at the time when they are executed is required in order to put an end to, or to prevent the occurrence of, circumstances then existing or imminent (or which the person responsible for the works believes on reasonable grounds to be existing or imminent) which are likely to cause danger to persons or property.

(2)Where works comprise items some of which fall within the preceding definition, the expression “emergency works” shall be taken to include such of the items as do not fall within that definition as cannot reasonably be severed from those that do.

(3)Where in any civil or criminal proceedings brought by virtue of any provision of this Part the question arises whether works were emergency works, it is for the person alleging that they were to prove it.

Textual Amendments

Modifications etc. (not altering text)

C247S. 52 excluded (27.11.1992) by S.I. 1992/2984, art. 5

The street works registerE+W

53 The street works register.E+W

(1)A street authority shall keep a register showing with respect to each street for which they are responsible such information as may be prescribed with respect to the street works, and such other descriptions of works as may be prescribed, executed or proposed to be executed in the street.

(2)The register shall contain such other information, and shall be kept in such form and manner, as may be prescribed.

(3)The authority shall make the register available for inspection, at all reasonable hours and free of charge—

(a)so far as it relates to restricted information, by any person having authority to execute works of any description in the street, or otherwise appearing to the authority to have a sufficient interest, and

(b)so far as it relates to information which is not restricted, by any person.

The Secretary of State may make provision by regulations as to the information which is restricted for the purposes of this subsection.

(4)The Secretary of State may make arrangements for the duties of street authorities under this section to be discharged by means of one or more central registers kept by a person appointed in pursuance of the arrangements.

[F14(4A)In subsection (4) “central register” means a register covering the areas of two or more street authorities.]

(5)If such arrangements are made the Secretary of State may require street authorities to participate in and make contributions towards the cost of the arrangements.

[F15(5A)In particular the Secretary of State may require a street authority to share information in their possession with a person appointed to keep a central register which discharges the duties of that authority under this section.]

(6)The Secretary of State may by regulations make provision with respect to any register kept in pursuance of this section—

(a)requiring the registration of such information as may be prescribed, and

(b)requiring the payment of such fee as may be prescribed in respect of the registration of information of any prescribed description;

and the regulations may contain provision as to the person responsible for securing the registration of the information and the person liable to pay the fee.

Textual Amendments

Modifications etc. (not altering text)

C248S. 53: functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(a)

Commencement Information

I1S. 53 wholly in force: s. 53(1)-(3) in force at 28.11.1992 see s. 170(1) and S.I. 1992/2984, art. 2(1), Sch. 1; s. 53(4)-(6) in force at 14.7.1992 by S.I. 1992/1686, art. 3, Sch.

Notice and co-ordination of worksE+W

54 Advance notice of certain works.E+W

(1)In such cases as may be prescribed an undertaker proposing to execute street works shall give the prescribed advance notice of the works to the street authority.

(2)Different periods of notice may be prescribed for different descriptions of works.

(3)The notice shall [F16state the date on which it is proposed to begin the works and shall contain such other] information as may be prescribed.

(4)After giving advance notice under this section an undertaker shall comply with such requirements as may be prescribed, or imposed by the street authority, as to the providing of information and other procedural steps to be taken for the purpose of co-ordinating the proposed works with other works of any description proposed to be executed in the street.

[F17(4A)If an undertaker who has given advance notice under this section has not, before the starting date specified in the notice, given to the street authority a notice under section 55 in respect of the works, he shall within such period as may be prescribed give to that authority a notice containing such information as may be prescribed.

(4B)An advance notice under this section shall cease to have effect in relation to the proposed works (so that subsection (1) applies again in relation to the works) if those works are not substantially begun before the end of such period beginning with the starting date specified in the notice as may be prescribed, or such further period as the street authority may allow.

(4C)Different periods may be prescribed under subsection (4B) for different descriptions of works.]

(5)An undertaker who fails to comply with his duties under this section commits an offence and is liable on summary conviction to a fine not exceeding [F18level 4] on the standard scale.

Textual Amendments

F16Words in s. 54(3) substituted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E. in so far as not already in force, 1.4.2008 for W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 49(1)(a), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 5); S.I. 2007/3174, art. 2, Sch. (with art. 6)

F17S. 54(4A)-(4C) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E. in so far as not already in force, 1.4.2008 for W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 49(1)(b), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 5); S.I. 2007/3174, art. 2, Sch. (with art. 6)

F18Words in s. 54(5) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C338S. 54 modified (27.11.1992) by S.I. 1992/2984, art. 3(1)

C339S. 54 applied (4.4.1996) by S.I. 1996/937, art. 8(4)(5)

S. 54 applied (13.1.1999) by S.I. 1998/3269, art. 4(2)(3)(4)

S. 54 applied (27.8.1998) by S.I. 1998/1936, art. 4(3)

S. 54 applied (21.5.1997) by S.I. 1997/1266, art. 5(2)(3)

S. 54 applied (10.2.1997) by S.I. 1997/264, art. 8(6)(7)

C340S. 54 applied (with modifications) (11.11.1996) by S.I. 1996/2714, art. 4(2)(3)

C341S. 54 applied (with modifications) (30.4.1999) by S.I. 1999/1306, art. 8(4)(5)

S. 54 applied (with modifications) (21.7.1999) by S.I. 1999/2129, art. 8(5)(6)

S. 54 applied (with modifications) (20.8.1999) by S.I. 1999/2336, art. 9(5)(6)(8)

S. 54 applied (with modifications) (23.8.1999) by S.I. 1999/2981, art. 7(5)(6)

S. 54 applied (with modifications) (29.3.2001) by S.I. 2001/1348, art. 21(3)-(5)

S. 54 applied (with modifications) (29.3.2001) by S.I. 2001/1347, art. 3(3)(4)

S. 54 applied (with modifications) (18.7.2001) by S.I. 2001/2870, art. 10(6)

S. 54 applied (with modifications) (24.7.2001) by S.I. 2001/3627, art. 4(3)(4)

S. 54 applied (with modifications) (9.11.2001) by S.I. 2001/3682, art. 8(6)

C343S. 54 applied (with modifications) (28.4.2003) by The Network Rail (West Coast Main Line) Order 2003 (S.I. 2003/1075), arts. 1, 13(6)(7)(8) (with art. 40)

C351S. 54 applied (with modifications) (26.8.2005) by The River Tyne (Tunnels) Order 2005 (S.I. 2005/2222), arts. 1, 8(9)(10) (with arts. 45(1), 48, Sch. 10 paras. 21, 29)

C354S. 54 applied (with modifications) (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(3)(4) (with art. 52)

C358S. 54 applied (with modifications) (13.12.2006) by The Network Rail (Thameslink 2000) Order 2006 (S.I. 2006/3117), arts. 1, 16(6)(7) (with arts. 34, 35(2))

C359S. 54 applied (with modifications) (13.12.2006) by The Luton Dunstable Translink Order 2006 (S.I. 2006/3118), arts. 1, 10(5)(6)

C360S. 54 applied (with modifications) (19.3.2007) by The Ouseburn Barrage Order 2007 (S.I. 2007/608), arts. 1, 8(2)(3) (with arts. 46-48, Sch. 6 para. 23)

C389S. 54 applied (with modifications) (20.7.2010) by The Network Rail (Nuneaton North Chord) Order 2010 (S.I. 2010/1721), arts. 1, 4

C407S. 54 applied (with modifications) (26.9.2012) by The Network Rail (Ipswich Chord) Order 2012 (S.I. 2012/2284), arts. 1, 10(2)(3) (with art. 26(2))

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C432S. 54 applied (with modifications) (21.8.2013) by The Croxley Rail Link Order 2013 (S.I. 2013/1967), arts. 1, 4(1)-(3)

C450S. 54 applied (with modifications) (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(4) (with art. 31(2))

C455S. 54 applied (with modifications) (2.10.2014) by The Clocaenog Forest Wind Farm Order 2014 (S.I. 2014/2441), arts. 1, 13(2)-(4) (with art. 33)

C461S. 54 applied (with modifications) (31.12.2014) by The Hornsea One Offshore Wind Farm Order 2014 (S.I. 2014/3331), arts. 1, 7(1)-(3) (with arts. 37, 38)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C526S. 54 applied (with modifications) (18.4.2018) by The Network Rail (Hope Valley Capacity) Order 2018 (S.I. 2018/446), arts. 1, 4(3)-(5) (with arts. 24(8), 33(2))

C527S. 54 applied (with modifications) (31.5.2018) by The Silvertown Tunnel Order 2018 (S.I. 2018/574), arts. 1(2), 7(4)-(6)

C530S. 54 applied (with modifications) (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(4)-(6) (with arts. 55, 56)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C557S. 54 applied (with modifications) (25.3.2022) by The Bridgwater Tidal Barrier Order 2022 (S.I. 2022/299), arts. 1, 3(4)(5) (with art. 55)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C578S. 54 applied (with modifications) (10.3.2023) by The A47 Wansford to Sutton Development Consent Order 2023 (S.I. 2023/218), arts. 1, 11(4)-(6) (with arts. 4, 50)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C600S. 54 excluded (4.10.2024) by The National Grid (Bramford to Twinstead Reinforcement) Order 2024 (S.I. 2024/958), arts. 1, 13(4) (with art. 40, Sch. 14)

S. 54 applied (with modifications) (9.10.2024) by The M3 Junction 9 Development Consent Order 2024 (S.I. 2024/753), arts. 1, 13(4)-(6) (with arts. 4, 13(8), Sch. 10) (as amended by S.I. 2024/1020, Sch.)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C614S. 54 applied (with modifications) (14.8.2025) by The Byers Gill Solar Order 2025 (S.I. 2025/934), arts. 1, 10(3)-(5) (with art. 43, Sch. 11)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

C625S. 54 applied (with modifications) (25.2.2026) by The A46 Coventry Junctions (Walsgrave) Development Consent Order 2026 (S.I. 2026/125), arts. 1, 10(4)-(6) (with arts. 40, 45, Sch. 9) (which affecting provisions were superseded by S.I. 2026/537, arts. 1, 10(4)-(6) (with arts. 40, 45, Sch. 9))

C629S. 54 applied (with modifications) (23.7.2026) by The Peartree Hill Solar Farm Order 2026 (S.I. 2026/869), arts. 1, 11(4)-(6) (with art. 37, Sch. 11)

C630S. 54 applied (with modifications) (24.7.2026) by The Dean Moor Solar Farm Order 2026 (S.I. 2026/754), arts. 1, 11(4)-(6) (with Sch. 13)

C634S. 54(1)(4): functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(b)

55 Notice of starting date of works.E+W

(1)An undertaker proposing to begin to execute street works involving—

(a)breaking up or opening the street, or any sewer, drain or tunnel under it, or

(b)tunnelling or boring under the street,

shall give not less than 7 working days’ notice (or such other notice as may be prescribed) to the street authority, to any other relevant authority and to any other person having apparatus in the street which is likely to be affected by the works.

(2)Different periods of notice may be prescribed for different descriptions of works, [F19or in cases where the undertaker has been given notice under section 58(1),] and cases may be prescribed in which no notice is required.

(3)The notice shall state the date on which it is proposed to begin the works and shall contain such other information as may be prescribed.

(4)Where notice is required to be given under this section, the works shall not be begun without notice or before the end of the notice period, except with the consent of those to whom notice is required to be given.

(5)An undertaker who begins to execute any works in contravention of this section commits an offence and is liable on summary conviction to a fine not exceeding [F20level 4] on the standard scale.

(6)In proceedings against a person for such an offence it is a defence for him to show that the contravention was attributable—

(a)to his not knowing the position, or not knowing of the existence, of another person’s apparatus, or

(b)to his not knowing the identity or address of—

(i)a relevant authority, or

(ii)the person to whom any apparatus belongs,

and that his ignorance was not due to any negligence on his part or to any failure to make inquiries which he ought reasonably to have made.

(7)A notice under this section shall cease to have effect if the works to which it relates are not substantially begun before the end of the period of 7 working days (or such other period as may be prescribed) beginning with the starting date specified in the notice, or such further period as may be allowed by those to whom notice is required to be given.

[F21(8)If a notice under this section ceases to have effect the undertaker shall, within such period as may be prescribed, give a notice containing such information as may be prescribed to those to whom the notice under this section was required to be given.

(9)An undertaker who fails to give notice in accordance with subsection (8) commits an offence and is liable on summary conviction to a fine not exceeding level 4 on the standard scale.]

Textual Amendments

F19Words in s. 55(2) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E. in so far as not already in force, 1.4.2008 for W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 51(9), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F20Words in s. 55(5) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

F21S. 55(8)(9) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E. in so far as not already in force, 1.4.2008 for W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 49(2), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 5); S.I. 2007/3174, art. 2, Sch. (with art. 6)

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

C636S. 55 applied (4.4.1996) by S.I. 1996/937, art. 8(4)(5)

S. 55 applied (13.1.1999) by S.I. 1998/3269, art. 4(2)(3)(4)

S. 55 applied (27.8.1998) by S.I. 1998/1936, art. 4(3)

S. 55 applied (21.5.1997) by S.I. 1997/1266, art. 5(2)(3)

S. 55 applied (10.2.1997) by S.I. 1997/264, art. 8(6)(7)

S. 55 applied with modifications (11.11.1996) by S.I. 1996/2714, art. 4(2)(3)

C637S. 55 applied (with modifications) (30.4.1999) by S.I. 1999/1306, art. 8(4)(5)

S. 55 applied (with modifications) (21.7.1999) by S.I. 1999/2129, art. 8(5)(6)

S. 55 applied (with modifications) (20.8.1999) by S.I. 1999/2336, art. 9(5)(6)(8)

S. 55 applied (with modifications) (23.8.1999) by S.I. 1999/2981, art. 7(5)(6)

S. 55 applied (with modifications) (29.3.2001) by S.I. 2001/1348, art. 21(3)-(5)

S. 55 applied (with modifications) (29.3.2001) by S.I. 2001/1347, art. 3(3)(4)

S. 55 applied (with modifications) (18.7.2001) by S.I. 2001/2870, art. 10(6)

S. 55 applied (with modifications) (24.7.2001) by S.I. 2001/3627, art. 4(3)(4)

S. 55 applied (with modifications) (9.11.2001) by S.I. 2001/3682, art. 8(6)

C645S. 55 applied (with modifications) (3.8.2005) by The Greater Manchester (Leigh Busway) Order 2005 (S.I. 2005/1918), arts. 1, 3(3)(4)

C646S. 55 applied (with modifications) (26.8.2005) by The River Tyne (Tunnels) Order 2005 (S.I. 2005/2222), arts. 1, 8(9)(10) (with arts. 45(1), 48, Sch. 10 paras. 21, 29)

C648S. 55 applied (with modifications) (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(3)(4) (with art. 52)

C652S. 55 applied (with modifications) (13.12.2006) by The Network Rail (Thameslink 2000) Order 2006 (S.I. 2006/3117), arts. 1, 16(6)(7) (with arts. 34, 35(2))

C653S. 55 applied (with modifications) (13.12.2006) by The Luton Dunstable Translink Order 2006 (S.I. 2006/3118), arts. 1, 10(5)(6)

C654S. 55 applied (with modifications) (19.3.2007) by The Ouseburn Barrage Order 2007 (S.I. 2007/608), arts. 1, 8(2)(3) (with arts. 46-48, Sch. 6 para. 23)

C701S. 55 applied (with modifications) (26.9.2012) by The Network Rail (Ipswich Chord) Order 2012 (S.I. 2012/2284), arts. 1, 10(2)(3) (with art. 26(2))

C722S. 55 applied (with modifications) (21.8.2013) by The Croxley Rail Link Order 2013 (S.I. 2013/1967), arts. 1, 4(1)-(3)

C738S. 55 applied (with modifications) (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(4) (with art. 31(2))

C741S. 55 applied (with modifications) (2.10.2014) by The Clocaenog Forest Wind Farm Order 2014 (S.I. 2014/2441), arts. 1, 13(2)-(4) (with art. 33)

C745S. 55 applied (with modifications) (31.12.2014) by The Hornsea One Offshore Wind Farm Order 2014 (S.I. 2014/3331), arts. 1, 7(1)-(3) (with arts. 37, 38)

C787S. 55 applied (with modifications) (31.5.2018) by The Silvertown Tunnel Order 2018 (S.I. 2018/574), arts. 1(2), 7(4)-(6)

C789S. 55 applied (with modifications) (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(4)-(6) (with arts. 55, 56)

C797S. 55 applied (with modifications) (19.6.2020) by The Cleve Hill Solar Park Order 2020 (S.I. 2020/547), arts. 1, 9(2)(a)(h) (with arts. 9(3), 37)

C809S. 55 applied (with modifications) (25.3.2022) by The Bridgwater Tidal Barrier Order 2022 (S.I. 2022/299), arts. 1, 3(4)(5) (with art. 55)

C832S. 55 applied (with modifications) (11.10.2023) by The Awel y Môr Offshore Wind Farm Order 2023 (S.I. 2023/1033), arts. 1, 10(1)-(3) (with arts. 36, 37, Sch. 9 paras. 14, 44(1), 76, 103)

C840S. 55 applied (with modifications) (4.10.2024) by The National Grid (Bramford to Twinstead Reinforcement) Order 2024 (S.I. 2024/958), arts. 1, 13(5)-(7) (with art. 40, Sch. 14)

S. 55 applied (with modifications) (9.10.2024) by The M3 Junction 9 Development Consent Order 2024 (S.I. 2024/753), arts. 1, 13(4)-(6) (with arts. 4, 13(8), Sch. 10) (as amended by S.I. 2024/1020, Sch.)

C846S. 55 applied (with modifications) (28.4.2025) by The Rampion 2 Offshore Wind Farm Order 2025 (S.I. 2025/468), arts. 1, 10(2)(3) (with arts. 47, 48, Sch. 10)

C849S. 55 applied (with modifications) (28.7.2025) by The Mona Offshore Wind Farm Order 2025 (S.I. 2025/870), arts. 1, 11(1)-(3) (with arts. 37, 38, Sch. 10)

C850S. 55 applied (with modifications) (14.8.2025) by The Byers Gill Solar Order 2025 (S.I. 2025/934), arts. 1, 10(3)-(5) (with art. 43, Sch. 11)

C854S. 55 applied (with modifications) (29.12.2025) by The Helios Renewable Energy Project Order 2025 (S.I. 2025/1372), arts. 1, 11(1)-(3) (with Sch. 9)

C856S. 55 applied (with modifications) (25.2.2026) by The A46 Coventry Junctions (Walsgrave) Development Consent Order 2026 (S.I. 2026/125), arts. 1, 10(4)-(6) (with arts. 40, 45, Sch. 9) (which affecting provisions were superseded by S.I. 2026/537, arts. 1, 10(4)-(6) (with arts. 40, 45, Sch. 9))

C857S. 55 applied (with modifications) (4.3.2026) by The Outer Dowsing Offshore Wind Farm Order 2026 (S.I. 2026/138), arts. 1(2), 9(1)-(3) (with arts. 42, 43, Sch. 18)

C860S. 55 applied (with modifications) (23.7.2026) by The Peartree Hill Solar Farm Order 2026 (S.I. 2026/869), arts. 1, 11(4)-(6) (with art. 37, Sch. 11)

C861S. 55 applied (with modifications) (24.7.2026) by The Dean Moor Solar Farm Order 2026 (S.I. 2026/754), arts. 1, 11(4)-(6) (with Sch. 13)

C862S. 55(1)(4): functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(c)

Commencement Information

I2S. 55 wholly in force: s. 55 in force for the purpose of making regulations at 28.11.1992, and for all other purposes at 1.1.1993, see s. 170 and S.I. 1992/2984, art. 2, Schs. 1, 2

56 Power to give directions as to timing of street works.E+W

(1)If it appears to the street authority—

(a)that proposed street works are likely to cause serious disruption to traffic, and

(b)that the disruption would be avoided or reduced if the works were carried out only at certain times [F22or on certain days (or at certain times on certain days)],

the authority may give the undertaker such directions as may be appropriate as to the times [F22or days (or both)] when the works may or may not be carried out.

[F23(1A)Where it appears to a street authority—

(a)that subsisting street works are causing or are likely to cause serious disruption to traffic, and

(b)that the disruption would be avoided or reduced if the works were to continue to be carried out only at certain times or on certain days (or at certain times on certain days),

the authority may give the undertaker such directions as may be appropriate as to the times or days (or both) when the works may or may not continue to be carried out.]

(2)The procedure for giving a direction shall be prescribed by the Secretary of State.

(3)An undertaker who executes works in contravention of a direction under this section commits an offence and is liable on summary conviction to a fine not exceeding [F24level 5] on the standard scale.

[F25(3A)An undertaker shall be taken not to have failed to fulfil any statutory duty to afford a supply or service if, or to the extent that, his failure is attributable to a direction under this section.]

(4)The Secretary of State may issue or approve for the purposes of this section a code of practice giving practical guidance as to the exercise by street authorities of the power conferred by this section; and in exercising that power a street authority shall have regard to the code of practice.

Textual Amendments

F24Words in s. 56(3) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

C863S. 56 excluded (11.11.1996) by S.I. 1996/2714, art. 4(1)

S. 56 excluded (27.8.1998) by S.I. 1998/1936, art. 4(1)

S. 56 excluded (21.5.1997) by S.I. 1997/1266, art. 5(1)

S. 56 excluded (24.7.2001) by S.I. 2001/3627, art. 4(2)

C1014S. 56 excluded (11.10.2023) by The Awel y Môr Offshore Wind Farm Order 2023 (S.I. 2023/1033), arts. 1, 10(4) (with arts. 36, 37, Sch. 9 paras. 14, 44(1), 76, 103)

C1034S. 56 excluded (25.2.2026) by The A46 Coventry Junctions (Walsgrave) Development Consent Order 2026 (S.I. 2026/125), arts. 1, 10(3) (with arts. 40, 45, Sch. 9) (which affecting provisions were superseded by S.I. 2026/537, arts. 1, 10(3) (with arts. 40, 45, Sch. 9))

C1037S. 56(1)(4): functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(d)

[F2656APower to give directions as to placing of apparatusE+W

(1)Where—

(a)an undertaker is proposing to execute street works consisting of the placing of apparatus in a street (“street A”),

(b)placing the apparatus in street A is likely to cause disruption to traffic, and

(c)it appears to the street authority that—

(i)there is another street (“street B”) in which the apparatus could be placed, and

(ii)the conditions in subsection (2) are satisfied,

the authority may by direction require the undertaker not to place the apparatus in street A (but may not require him to place the apparatus in street B).

(2)The conditions referred to in subsection (1)(c) are that—

(a)disruption to traffic would be avoided or reduced if the apparatus were to be placed in street B;

(b)placing the apparatus in street B would be a reasonable way of achieving the purpose for which the apparatus is to be placed; and

(c)it is reasonable to require the undertaker not to place the apparatus in street A.

(3)A direction under this section may be varied or revoked by a further such direction.

(4)The procedure for giving a direction under this section shall be prescribed by the Secretary of State.

(5)The Secretary of State may by regulations make provision for appeals against directions under this section, including provision as to the persons who may determine appeals and the procedure to be followed on an appeal.

(6)An undertaker who executes works in contravention of a direction under this section commits an offence and is liable on summary conviction to a fine not exceeding level 5 on the standard scale.

(7)An undertaker shall be taken not to have failed to fulfil any statutory duty to afford a supply or service if, or to the extent that, his failure is attributable to a direction under this section.

(8)The Secretary of State may issue or approve for the purposes of this section a code of practice giving practical guidance as to the exercise by street authorities of the power conferred by this section; and in exercising that power a street authority shall have regard to the code of practice.]

Textual Amendments

F26S. 56A inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 44, 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 4); S.I. 2007/3174, art. 2, Sch. (with art. 5)

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

C1111S. 56A excluded (11.10.2023) by The Awel y Môr Offshore Wind Farm Order 2023 (S.I. 2023/1033), arts. 1, 10(4) (with arts. 36, 37, Sch. 9 paras. 14, 44(1), 76, 103)

C1125S. 56A excluded (28.7.2025) by virtue of The Mona Offshore Wind Farm Order 2025 (S.I. 2025/870), arts. 1, 11(4) (with arts. 37, 38, Sch. 10)

C1131S. 56A excluded (25.2.2026) by The A46 Coventry Junctions (Walsgrave) Development Consent Order 2026 (S.I. 2026/125), arts. 1, 10(3) (with arts. 40, 45, Sch. 9) (which affecting provisions were superseded by S.I. 2026/537, arts. 1, 10(3) (with arts. 40, 45, Sch. 9))

57 Notice of emergency works.E+W

(1)Nothing in section 54 (advance notice), section 55 (notice of starting date) or section 56 (directions as to timing of works) [F27or paragraph 2(1)(d) or 3(1) of Schedule 3A (notification of proposed works or directions as to timings of works)] affects the right of an undertaker to execute emergency works.

(2)An undertaker executing emergency works shall, if the works are of a kind in respect of which notice is [F28(or would, but for paragraph 2(6) of Schedule 3A, be)] required by section 55, give notice as soon as reasonably practicable, and in any event within two hours (or such other period as may be prescribed) of the works being begun, to the persons to whom notice would be required to be given under that section.

(3)The notice shall state his intention or, as the case may be, the fact that he has begun to execute the works and shall contain such other information as may be prescribed.

(4)An undertaker who fails to give notice in accordance with this section commits an offence and is liable on summary conviction to a fine not exceeding [F29level 4] on the standard scale.

(5)In proceedings against a person for such an offence it is a defence for him to show that the contravention was attributable—

(a)to his not knowing the position, or not knowing of the existence, of another person’s apparatus, or

(b)to his not knowing the identity or address of—

(i)a relevant authority, or

(ii)the person to whom any apparatus belongs,

and that his ignorance was not due to any negligence on his part or to any failure to make inquiries which he ought reasonably to have made.

Textual Amendments

F29Words in s. 57(4) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

C1135S. 57 modified (27.11.1992) by S.I. 1992/2984, art. 5

C1136S. 57 applied (with modifications) (11.11.1996) by S.I. 1996/2714, art. 4(2)(3)

S. 57 applied (27.8.1998) by S.I. 1998/1936, art. 4(3)

S. 57 applied (21.5.1997) by S.I. 1997/1266, art. 5(2)(3)

S. 57 applied (with modifications) (24.7.2001) by S.I. 2001/3627, art. 4(3)(4)

C1140S. 57 applied (with modifications) (3.8.2005) by The Greater Manchester (Leigh Busway) Order 2005 (S.I. 2005/1918), arts. 1, 3(3)(4)

C1142S. 57 applied (with modifications) (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(4) (with arts. 3(5), 15(3))

C1143S. 57 applied (with modifications) (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(3)(4) (with art. 52)

C1212S. 57 applied (with modifications) (21.8.2013) by The Croxley Rail Link Order 2013 (S.I. 2013/1967), arts. 1, 4(1)(2)

C1213S. 57 applied (with modifications) (22.8.2013) by The Leeds Railway Station (Southern Entrance) Order 2013 (S.I. 2013/1933), arts. 1, 3(3)(4)

C1227S. 57 applied (with modifications) (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(4) (with art. 31(2))

C1233S. 57 applied (with modifications) (31.12.2014) by The Hornsea One Offshore Wind Farm Order 2014 (S.I. 2014/3331), arts. 1, 7(1)(2) (with arts. 37, 38)

C1260S. 57 applied (with modifications) (7.9.2016) by The Hornsea Two Offshore Wind Farm Order 2016 (S.I. 2016/844), arts. 1(2), 10(2)(c) (with arts. 37, 38)

C1269S. 57 applied (with modifcations) (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(4)(5) (with arts. 55-57, Sch. 8 para. 13)

C1274S. 57 applied (with modifications) (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(4)(5) (with arts. 55, 56)

C1282S. 57 applied (with modifications) (19.6.2020) by The Cleve Hill Solar Park Order 2020 (S.I. 2020/547), arts. 1, 9(2)(b)(h) (with art. 37)

C1284S. 57 applied (with modifications) (6.8.2020) by The A19 Downhill Lane Junction Development Consent Order 2020 (S.I. 2020/746), arts. 1, 9(4)(5) (with art. 5)

C1292S. 57 applied (with modifications) (5.3.2022) by The Norfolk Vanguard Offshore Wind Farm Order 2022 (S.I. 2022/138), arts. 1, 14(1)(2) (with arts. 41, 42, Sch. 16)

C1294S. 57 applied (with modifications) (25.3.2022) by The Bridgwater Tidal Barrier Order 2022 (S.I. 2022/299), arts. 1, 3(4)-(6) (with art. 55)

C1296S. 57 applied (with modifications) (22.4.2022) by The East Anglia TWO Offshore Wind Farm Order 2022 (S.I. 2022/433), arts. 1(2), 9(1)(2)(b) (with arts. 40, 41)

C1316S. 57 applied (11.10.2023) by The Awel y Môr Offshore Wind Farm Order 2023 (S.I. 2023/1033), arts. 1, 10(1)(2) (with arts. 36, 37, Sch. 9 paras. 14, 44(1), 76, 103)

C1317S. 57 applied (9.2.2024) by The A12 Chelmsford to A120 Widening Development Consent Order 2024 (S.I. 2024/60), arts. 1, 12(4)(5) (with arts. 4, 52, Sch. 11 paras. 6, 24, 39(1), 55(1), 84)

C1325S. 57 excluded (4.10.2024) by The National Grid (Bramford to Twinstead Reinforcement) Order 2024 (S.I. 2024/958), arts. 1, 13(4) (with art. 40, Sch. 14)

S. 57 applied (9.10.2024) by The M3 Junction 9 Development Consent Order 2024 (S.I. 2024/753), arts. 1, 13(4)(5) (with arts. 4, 13(8), Sch. 10) (as amended by S.I. 2024/1020, Sch.)

S. 57 applied (9.10.2024) by The M3 Junction 9 Development Consent Order 2024 (S.I. 2024/753), arts. 1, 13(4)(5) (with arts. 4, 13(8), Sch. 10) (as amended by S.I. 2024/1020, Sch.)

C1339S. 57 applied (with modifications) (8.1.2026) by The Five Estuaries Offshore Wind Farm Order 2025 (S.I. 2025/1376), arts. 1, 11(1)(2) (with arts. 39, 40, Sch. 9)

C1340S. 57 applied (25.2.2026) by The A46 Coventry Junctions (Walsgrave) Development Consent Order 2026 (S.I. 2026/125), arts. 1, 10(4)(5) (with arts. 40, 45, Sch. 9) (which affecting provisions were superseded by S.I. 2026/537, arts. 1, 10(4)(5) (with arts. 40, 45, Sch. 9))

58 Restriction on works following substantial road works.E+W

(1)Where it is proposed to carry out substantial road works in a highway, the street authority may by notice in accordance with this section restrict the execution of street works during the [F30prescribed period] following the completion of those works.

For this purpose substantial road works means works for road purposes, or such works together with other works, of such description as may be prescribed.

(2)The notice shall be published in the prescribed [F31form and] manner and shall specify the nature and location of the proposed works, the date (not being less than [F32such period as may be prescribed] after the notice is published, or first published) on which it is proposed to begin the works, and the extent of the restriction.

(3)A copy of the notice shall be given to each of the following—

(a)where there is a public sewer in the part of the highway to which the restriction relates, to the sewer authority,

(b)where the part of the highway to which the restriction relates is carried or crossed by a bridge vested in a transport authority, or crosses or is crossed by any other property held or used for the purposes of a transport authority, to that authority,

(c)where in any other case the part of the highway to which the restriction relates is carried or crossed by a bridge, to the bridge authority,

(d)any person who has given notice under section 54 (advance notice of certain works) of his intention to execute street works in the part of the highway to which the restriction relates, F33...

(e)any other person having apparatus in the part of the highway to which the restriction relates; [F34and

(f)any other person of a prescribed description;]

but a failure to do so does not affect the validity of the restriction imposed by the notice.

(4)A notice ceases to be effective if the works to which it relates are not substantially begun [F35within such period as may be prescribed].

(5)An undertaker shall not in contravention of a restriction imposed by a notice under this section break up or open the part of the highway to which the restriction relates, except—

(a)to execute emergency works,

(b)with the consent of the street authority, or

(c)in such other cases as may be prescribed.

(6)If he does—

(a)he commits an offence and is liable on summary conviction to a fine not exceeding [F36level 5] on the standard scale, and

(b)[F37if he is convicted of an offence under this subsection] he is liable to reimburse the street authority any costs reasonably incurred by them in reinstating the highway.

(7)The consent of the street authority under subsection (5)(b) shall not be unreasonably withheld; and any question whether the withholding of consent is unreasonable shall be settled [F38in the prescribed manner].

[F39(7A)Regulations under subsection (7) may in particular make provision for the question referred to in that subsection to be settled—

(a)by arbitration;

(b)by a person designated by the Secretary of State on appeal by the undertaker.]

(8)An undertaker shall be taken not to have failed to fulfil any statutory duty to afford a supply or service if, or to the extent that, his failure is attributable to a restriction imposed by a notice under this section.

Textual Amendments

F30Words in s. 58(1) substituted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 51(2), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F31Words in s. 58(2) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 51(3), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F32Words in s. 58(2) substituted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 51(3), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F33Word in s. 58(3) repealed (29.6.2007 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 51(4), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F34S. 58(3)(f) and word inserted (29.6.2007 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 51(4), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F35Words in s. 58(4) substituted for s. 58(4)(a)(b) (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 51(5), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F36Words in s. 58(6)(a) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

F37Words in s. 58(6)(b) inserted (1.4.2008) by Traffic Management Act 2004 (c. 18), ss. 51(6), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F38Words in s. 58(7) substituted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 51(7), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F39S. 58(7A) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 51(8), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

C1346S. 58 restricted (27.11.1992) by S.I. 1992/2984, art. 6

C1347S. 58 excluded (11.11.1996) by S.I. 1996/2714, art. 4(1)

S. 58 excluded (27.8.1998) by S.I. 1998/1936, art. 4(1)

S. 58 excluded (21.5.1997) by S.I. 1997/1266, art. 5(1)

S. 58 excluded (24.7.2001) by S.I. 2001/3627, art. 4(2)

S. 58: functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(e)

C1497S. 58 excluded (11.10.2023) by The Awel y Môr Offshore Wind Farm Order 2023 (S.I. 2023/1033), arts. 1, 10(4) (with arts. 36, 37, Sch. 9 paras. 14, 44(1), 76, 103)

C1504S. 58 excluded (4.10.2024) by The National Grid (Bramford to Twinstead Reinforcement) Order 2024 (S.I. 2024/958), arts. 1, 13(3) (with art. 40, Sch. 14)

S. 58 excluded (9.10.2024) by The M3 Junction 9 Development Consent Order 2024 (S.I. 2024/753), arts. 1, 13(3) (with arts. 4, 13(8), Sch. 10) (as amended by S.I. 2024/1020, Sch.)

S. 58 excluded (9.10.2024) by The M3 Junction 9 Development Consent Order 2024 (S.I. 2024/753), arts. 1, 13(3) (with arts. 4, 13(8), Sch. 10) (as amended by S.I. 2024/1020, Sch.)

[F4058ARestriction on works following substantial street worksE+W

Schedule 3A shall have effect.]

Textual Amendments

F40S. 58A inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 52(1), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 7); S.I. 2007/3174, art. 2, Sch. (with art. 8)

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

C1646S. 58A excluded (11.10.2023) by The Awel y Môr Offshore Wind Farm Order 2023 (S.I. 2023/1033), arts. 1, 10(4) (with arts. 36, 37, Sch. 9 paras. 14, 44(1), 76, 103)

C1664S. 58A excluded (25.2.2026) by The A46 Coventry Junctions (Walsgrave) Development Consent Order 2026 (S.I. 2026/125), arts. 1, 10(3) (with arts. 40, 45, Sch. 9) (which affecting provisions were superseded by S.I. 2026/537, arts. 1, 10(3) (with arts. 40, 45, Sch. 9))

59 General duty of street authority to co-ordinate works.E+W

(1)A street authority shall use their best endeavours to co-ordinate the execution of works of all kinds (including works for road purposes) [F41and the carrying out of relevant activities] in the streets for which they are responsible—

(a)in the interests of safety,

(b)to minimise the inconvenience to persons using the street (having regard, in particular, to the needs of people with a disability), and

(c)to protect the structure of the street and the integrity of apparatus in it.

(2)That duty extends to co-ordination with other street authorities where works [F42or relevant activities] in a street for which one authority are responsible affect streets for which other authorities are responsible.

(3)The Secretary of State shall issue or approve for the purposes of this section codes of practice giving practical guidance as to the matters mentioned above; and in discharging their general duty of co-ordination a street authority shall have regard to any such code of practice.

(4)If it appears to the Secretary of State that a street authority are not properly discharging their general duty of co-ordination, he may direct the authority to supply him with such information as he considers necessary to enable him to decide whether that is the case and if so what action to take.

The direction shall specify the information to be provided and the period within which it is to be provided.

(5)If after the end of that period (whether or not the direction has been complied with) it appears to the Secretary of State that the authority are not properly discharging their general duty of co-ordination, he may direct the authority to take such steps as he considers appropriate for the purpose of discharging that duty.

The direction shall specify the steps to be taken and the period within which they are to be taken, and may include a requirement to make a report or periodic reports to the Secretary of State as to what steps have been taken and the results of taking them.

(6)A direction under this section may be varied or revoked by a further direction.

[F43(7)In this section “relevant activities” means any activity, other than the execution of works in the street or the use of the street by traffic (including pedestrians), which—

(a)involves the temporary occupation or use of space in a street;

(b)is subject to regulation by the street authority by virtue of provision made by or under any Act other than this Act; and

(c)is prescribed by regulations made by the Secretary of State.]

Textual Amendments

F41Words in s. 59(1) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes) by Traffic Management Act 2004 (c. 18), ss. 42(2), 99(1); S.I. 2007/1890, art. 2, Sch.; S.I. 2007/3174, art. 2, Sch.

F42Words in s. 59(2) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes) by Traffic Management Act 2004 (c. 18), ss. 42(3), 99(1); S.I. 2007/1890, art. 2, Sch.; S.I. 2007/3174, art. 2, Sch.

F43S. 59(7) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes) by Traffic Management Act 2004 (c. 18), ss. 42(4), 99(1); S.I. 2007/1890, art. 2, Sch.; S.I. 2007/3174, art. 2, Sch.

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

C1667S. 59 applied (4.4.1996) by S.I. 1996/937, art. 8(4)(5)

S. 59 applied (13.1.1999) by S.I. 1998/3269, art. 4(2)(3)

S. 59 applied (27.8.1998) by S.I. 1998/1936, art. 4(3)

S. 59 applied (21.5.1997) by S.I. 1997/1266, art. 5(2)(3)

S. 59 applied (10.2.1997) by S.I. 1997/264, art. 8(6)(7)

S. 59 applied (with modifications) (30.4.1999) by S.I. 1999/1306, art. 8(4)(5)

S. 59 applied (with modifications) (21.7.1999) by S.I. 1999/2129, art. 8(5)(6)

S. 59 applied (with modifications) (20.8.1999) by S.I. 1999/2336, art. 9(5)(6)(8)

S. 59 applied (with modifications) (23.8.1999) by S.I. 1999/2981, art. 7(5)(6)

S. 59 applied (with modifications) (11.11.1996) by S.I. 1996/2714, art. 4(2)(3)

S. 59: functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(c)

S. 59 applied (with modifications) (29.3.2001) by S.I. 2001/1348, art. 21(3)-(5)

S. 59 applied (with modifications) (29.3.2001) by S.I. 2001/1347, art. 3(3)

S. 59 applied (with modifications) (18.7.2001) by S.I. 2001/2870, art. 10(6)

S. 59 applied (with modifications) (24.7.2001) by S.I. 2001/3627, art. 4(3)(4)

S. 59 applied (with modifications) (9.11.2001) by S.I. 2001/3682, art. 8(6)

C1669S. 59 applied (with modifications) (28.4.2003) by The Network Rail (West Coast Main Line) Order 2003 (S.I. 2003/1075), arts. 1, 13(6)(7)(8) (with art. 40)

C1671S. 59 applied (with modifications) (19.11.2004) by The Scarweather Sands Offshore Wind Farm Order 2004 (S.I. 2004/3054), arts. 1, 6(4)(5) (with art. 38)

C1677S. 59 applied (with modifications) (26.8.2005) by The River Tyne (Tunnels) Order 2005 (S.I. 2005/2222), arts. 1, 8(9)(10) (with arts. 45(1), 48, Sch. 10 paras. 21, 29)

C1679S. 59 applied (with modifications) (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(4) (with arts. 3(5), 15(3))

C1680S. 59 applied (with modifications) (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(3)(4) (with art. 52)

C1684S. 59 applied (with modifications) (13.12.2006) by The Network Rail (Thameslink 2000) Order 2006 (S.I. 2006/3117), arts. 1, 16(6)(7) (with arts. 34, 35(2))

C1685S. 59 applied (with modifications) (13.12.2006) by The Luton Dunstable Translink Order 2006 (S.I. 2006/3118), arts. 1, 10(5)(6)

C1686S. 59 applied (with modifications) (19.3.2007) by The Ouseburn Barrage Order 2007 (S.I. 2007/608), arts. 1, 8(2) (with arts. 46-48, Sch. 6 para. 23)

C1699S. 59 applied (with modifications) (21.8.2013) by The Croxley Rail Link Order 2013 (S.I. 2013/1967), arts. 1, 4(1)(2)

C1708S. 59 applied (with modifications) (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(4) (with art. 31(2))

C1713S. 59 applied (with modifications) (31.12.2014) by The Hornsea One Offshore Wind Farm Order 2014 (S.I. 2014/3331), arts. 1, 7(1)(2) (with arts. 37, 38)

C1715S. 59 applied (with modifications) (21.4.2015) by The Network Rail (Ordsall Chord) Order 2015 (S.I. 2015/780), arts. 1, 4(2)(3) (with art. 36(2))

C1722S. 59 applied (with modifications) (7.9.2016) by The Hornsea Two Offshore Wind Farm Order 2016 (S.I. 2016/844), arts. 1(2), 10(2)(d) (with arts. 37, 38)

C1731S. 59 applied (with modifcations) (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(4)(5) (with arts. 55-57, Sch. 8 para. 13)

C1737S. 59 applied (with modifications) (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(4)(5) (with arts. 55, 56)

C1754S. 59 applied (with modifications) (25.3.2022) by The Bridgwater Tidal Barrier Order 2022 (S.I. 2022/299), arts. 1, 3(4)(5) (with art. 55)

C1771S. 59 applied (with modifications) (27.7.2023) by The Boston Alternative Energy Facility Order 2023 (S.I. 2023/778), arts. 1, 11(4)(5) (with arts. 5, 53, Sch. 8 paras. 6, 64)

C1775S. 59 applied (9.2.2024) by The A12 Chelmsford to A120 Widening Development Consent Order 2024 (S.I. 2024/60), arts. 1, 12(4)(5) (with arts. 4, 52, Sch. 11 paras. 6, 24, 39(1), 55(1), 84)

C1789S. 59 applied (25.2.2026) by The A46 Coventry Junctions (Walsgrave) Development Consent Order 2026 (S.I. 2026/125), arts. 1, 10(4)(5) (with arts. 40, 45, Sch. 9) (which affecting provisions were superseded by S.I. 2026/537, arts. 1, 10(4)(5) (with arts. 40, 45, Sch. 9))

Commencement Information

I3S. 59 wholly in force: s. 59(1)(2)(4)-(6) in force at 1.1.1993, see s. 170 and S.I. 1992/2984, art. 2(2), Sch. 2; s. 59(3) in force at 14.7.1992 by S.I. 1992/1686, art. 3, Sch.

60 General duty of undertakers to co-operate.E+W

(1)An undertaker shall as regards the execution of street works use his best endeavours to co-operate with the street authority and with other undertakers—

(a)in the interests of safety,

(b)to minimise the inconvenience to persons using the street (having regard, in particular, to the needs of people with a disability), and

(c)to protect the structure of the street and the integrity of apparatus in it.

(2)The Secretary of State shall issue or approve for the purposes of this section codes of practice giving practical guidance as to the matters mentioned in subsection (1); and—

(a)so far as an undertaker complies with such a code of practice he shall be taken to comply with his duty under that subsection, and

(b)a failure in any respect to comply with any such code is evidence of failure in that respect to comply with that duty.

(3)An undertaker who fails to comply with his duty under subsection (1) commits an offence and is liable on summary conviction to a fine not exceeding [F44level 5] on the standard scale.

Textual Amendments

F44Words in s. 60(3) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

C1792S. 60 applied (4.4.1996) by S.I. 1996/937, art. 8(4)(5)

S. 60 applied (21.5.1997) by S.I. 1997/1266, art. 5(2)(3)

S. 60 applied (with modifications) (11.11.1996) by S.I. 1996/2714, art. 4(2)(3)

S. 60 applied (13.1.1999) by S.I. 1998/3269, art. 4(2)(3)

S. 60 applied (27.8.1998) by S.I. 1998/1936, art. 4(3)

S. 60 applied (10.2.1997) by S.I. 1997/264, art. 8(6)(7)

S. 60 applied (with modifications) (30.4.1999) by S.I. 1999/1306, art. 8(4)(5)

S. 60 applied (with modifications) (21.7.1999) by S.I. 1999/2129, art. 8(5)(6)

S. 60 applied (with modifications) (20.8.1999) by S.I. 1999/2336, art. 9(5)(6)(8)

S. 60 applied (with modifications) (23.8.1999) by S.I. 1999/2981, art. 7(5)(6)

S. 60 applied (with modifications) (29.3.2001) by S.I. 2001/1348, art. 21(3)-(5)

S. 60 applied (with modifications) (29.3.2001) by S.I. 2001/1347, art. 3(3)

S. 60 applied (with modifications) (18.7.2001) by S.I. 2001/2870, art. 10(6)

S. 60 applied (with modifications) (24.7.2001) by S.I. 2001/3627, art. 4(3)(4)

S. 60 applied (with modifications) (9.11.2001) by S.I. 2001/3682, art. 8(6)

C1794S. 60 applied (with modifications) (28.4.2003) by The Network Rail (West Coast Main Line) Order 2003 (S.I. 2003/1075), arts. 1, 13(6)(7)(8) (with art. 40)

C1796S. 60 applied (with modifications) (19.11.2004) by The Scarweather Sands Offshore Wind Farm Order 2004 (S.I. 2004/3054), arts. 1, 6(4)(5) (with art. 38)

C1802S. 60 applied (with modifications) (26.8.2005) by The River Tyne (Tunnels) Order 2005 (S.I. 2005/2222), arts. 1, 8(9)(10) (with arts. 45(1), 48, Sch. 10 paras. 21, 29)

C1803S. 60 applied (with modifications) (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(4) (with arts. 3(5), 15(3))

C1804S. 60 applied (with modifications) (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(3)(4) (with art. 52)

C1808S. 60 applied (with modifications) (13.12.2006) by The Network Rail (Thameslink 2000) Order 2006 (S.I. 2006/3117), arts. 1, 16(6)(7) (with arts. 34, 35(2))

C1809S. 60 applied (with modifications) (13.12.2006) by The Luton Dunstable Translink Order 2006 (S.I. 2006/3118), arts. 1, 10(5)(6)

C1810S. 60 applied (with modifications) (19.3.2007) by The Ouseburn Barrage Order 2007 (S.I. 2007/608), arts. 1, 8(2) (with arts. 46-48, Sch. 6 para. 23)

C1823S. 60 applied (with modifications) (21.8.2013) by The Croxley Rail Link Order 2013 (S.I. 2013/1967), arts. 1, 4(1)(2)

C1832S. 60 applied (with modifications) (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(4) (with art. 31(2))

C1837S. 60 applied (with modifications) (31.12.2014) by The Hornsea One Offshore Wind Farm Order 2014 (S.I. 2014/3331), arts. 1, 7(1)(2) (with arts. 37, 38)

C1839S. 60 applied (with modifications) (21.4.2015) by The Network Rail (Ordsall Chord) Order 2015 (S.I. 2015/780), arts. 1, 4(2)(3) (with art. 36(2))

C1846S. 60 applied (with modifications) (7.9.2016) by The Hornsea Two Offshore Wind Farm Order 2016 (S.I. 2016/844), arts. 1(2), 10(2)(e) (with arts. 37, 38)

C1855S. 60 applied (with modifications) (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(4)(5) (with arts. 55-57, Sch. 8 para. 13)

C1861S. 60 applied (with modifications) (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(4)(5) (with arts. 55, 56)

C1869S. 60 applied (with modifications) (19.6.2020) by The Cleve Hill Solar Park Order 2020 (S.I. 2020/547), arts. 1, 9(2)(c)(h) (with art. 37)

C1883S. 60 applied (with modifications) (25.3.2022) by The Bridgwater Tidal Barrier Order 2022 (S.I. 2022/299), arts. 1, 3(4)(5) (with art. 55)

C1907S. 60 applied (11.10.2023) by The Awel y Môr Offshore Wind Farm Order 2023 (S.I. 2023/1033), arts. 1, 10(1)(2) (with arts. 36, 37, Sch. 9 paras. 14, 44(1), 76, 103)

C1908S. 60 applied (9.2.2024) by The A12 Chelmsford to A120 Widening Development Consent Order 2024 (S.I. 2024/60), arts. 1, 12(4)(5) (with arts. 4, 52, Sch. 11 paras. 6, 24, 39(1), 55(1), 84)

C1930S. 60 applied (25.2.2026) by The A46 Coventry Junctions (Walsgrave) Development Consent Order 2026 (S.I. 2026/125), arts. 1, 10(4)(5) (with arts. 40, 45, Sch. 9) (which affecting provisions were superseded by S.I. 2026/537, arts. 1, 10(4)(5) (with arts. 40, 45, Sch. 9))

C1936S. 60(1): functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(g)

Commencement Information

I4S. 60 wholly in force: s. 60(1)(3) in force at 1.1.1993 see s. 170 and S.I. 1992/2984, art. 2(2), Sch. 2; s. 60(2) in force at 14.7.1992 by S.I. 1992/1686, art. 3, Sch.

Streets subject to special controlsE+W

61 Protected streets.E+W

(1)The consent of the street authority is required for the placing of apparatus by an undertaker in a protected street, except as mentioned below.

The following are “protected streets” for this purpose—

(a)any highway or proposed highway which is a special road in accordance with section 16 of the M3Highways Act 1980, and

(b)any street designated by the street authority as protected.

(2)Consent is not required for the placing of apparatus—

(a)by way of renewal of existing apparatus, or

(b)in pursuance of a street works licence,

unless, in the latter case, the licence was granted before the street became a protected street.

(3)The street authority may require the payment of—

(a)a reasonable fee in respect of the legal or other expenses incurred in connection with the giving of their consent under this section, and

(b)an annual fee of a reasonable amount for administering the consent;

and any such fee is recoverable from the undertaker.

This shall not be construed as affecting any right of the authority where they own the land on which the street is situated to grant for such consideration as they think fit the right to place anything in, under or over the land.

(4)Where the apparatus is to be placed crossing the protected street and not running along it, the street authority shall not withhold their consent unless there are special reasons for doing so.

(5)Consent to the placing of apparatus in a protected street may be given subject to conditions; and the street authority may agree to contribute to the expenses incurred by the undertaker in complying with the conditions.

(6)Any dispute between a street authority and an undertaker as to the withholding of consent, the imposition of conditions, or the making of contributions shall be settled by arbitration.

(7)An undertaker having a statutory duty to afford a supply or service shall not be regarded as in breach of that duty if, or to the extent that, it is not reasonably practicable to afford a supply or service by reason of anything done by the street authority in exercise of their functions under this section.

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

C1937S. 61 modified (27.11.1992) by S.I. 1992/2984, art. 7

S. 61: functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(h)

C1942S. 61 excluded (11.10.2023) by The Awel y Môr Offshore Wind Farm Order 2023 (S.I. 2023/1033), arts. 1, 10(4) (with arts. 36, 37, Sch. 9 paras. 14, 44(1), 76, 103)

Marginal Citations

62 Supplementary provisions as to designation of protected streets.E+W

(1)The Secretary of State may prescribe—

(a)the criteria for designating a street as protected,

(b)the procedure for making or withdrawing such a designation, and

(c)the information to be made available by a street authority as to the streets for the time being so designated by them.

(2)Where a street has been designated as protected the street authority may direct an undertaker to remove or change the position of apparatus placed in the street at a time when it was not so designated.

The authority shall indemnify the undertaker in respect of his reasonable expenses in complying with such a direction.

(3)Where a designation is withdrawn the street authority may give such directions as they consider appropriate as to—

(a)the continuance in force of any conditions subject to which consent was given for the placing of apparatus in the street, and

(b)the continuance of entitlement to any contributions in respect of the expenses of an undertaker in complying with such conditions.

(4)Where a designation is made or withdrawn the street authority may give such directions as they consider appropriate with respect to works in progress in the street when the designation comes into force or ceases to have effect.

(5)Any dispute between a street authority and an undertaker as to the exercise by the authority of their powers under subsection (2), (3) or (4) shall be settled by arbitration.

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

63 Streets with special engineering difficulties.E+W

(1)The provisions of Schedule 4 have effect for requiring the settlement of a plan and section of street works to be executed in a street designated by the street authority as having special engineering difficulties.

(2)The Secretary of State may prescribe—

(a)the criteria for designating a street as having special engineering difficulties,

(b)the procedure for making or withdrawing such a designation, and

(c)the information to be made available by a street authority as to the streets for the time being so designated by them.

(3)Where [F45a strategic highways company or] a local highway authority are asked to designate a street as having special engineering difficulties—

(a)by a transport authority on the ground of the proximity of the street to a structure belonging to, or under the management or control of, the authority, or

(b)by an undertaker having apparatus in the street,

and decline to do so, the transport authority or undertaker may appeal to the Secretary of State who may direct that the street be designated.

(4)The designation of a street as having special engineering difficulties shall not be withdrawn except after consultation with any transport authority or undertaker at whose request the designation was made; and a designation made in pursuance of a direction by the Secretary of State shall not be withdrawn except with his consent.

[F46(5)In addition to criteria for designation prescribed under subsection (2)(a), Schedule 3 to the Flood and Water Management Act 2010 requires designation in certain circumstances (relating to sustainable drainage systems).]

Textual Amendments

F46S. 63(5) inserted (2.5.2018 for W. for specified purposes, 7.1.2019 for W. in so far as not already in force) by Flood and Water Management Act 2010 (c. 29), s. 49(3), Sch. 3 para. 27 (with s. 49(1)(6)); S.I. 2018/557, arts. 2(b), 3(b)

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

64 Traffic-sensitive streets.E+W

(1)Regulations made for the purposes of section 54, 55 or 57 (notices required to be given in respect of street works) [F47or paragraph 2 of Schedule 3A] may make special provision in relation to street works in a street designated by the street authority as traffic-sensitive.

(2)The Secretary of State may prescribe—

(a)the criteria for designating a street as traffic-sensitive,

(b)the procedure for making or withdrawing such a designation, and

(c)the information to be made available by a street authority as to the streets for the time being so designated by them.

(3)If it appears to the street authority that the prescribed criteria are met only at certain times or on certain dates, a limited designation may be made accordingly.

In such a case the reference in subsection (1) to the execution of works in a street designated as traffic-sensitive shall be construed as a reference to works so executed at those times or on those dates.

[F48(4)Where any council of a London borough or the Common Council of the City of London are asked by the Traffic Director for London to designate a street as a traffic-sensitive street and they decline to do so, the Director may appeal to the Secretary of State who may direct that the street be designated.]

Textual Amendments

F47Words in s. 64(1) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 52(4), 99(1); S.I. 2007/1890, art. 2, Sch.; S.I. 2007/3174, art. 2, Sch.

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

General requirements as to execution of street worksE+W

65 Safety measures.E+W

(1)An undertaker executing street works shall secure—

(a)that any part of the street which is broken up or open, or is obstructed by plant or materials used or deposited in connection with the works, is adequately guarded and lit, and

(b)that such traffic signs are placed and maintained, and where necessary operated, as are reasonably required for the guidance or direction of persons using the street,

having regard, in particular, to the needs of people with a disability.

(2)In discharging in relation to a highway his duty with respect to the placing, maintenance or operation of traffic signs, an undertaker shall comply with any directions given by the traffic authority.

The power of the traffic authority to give directions under this subsection is exercisable subject to any directions given by the Secretary of State under section 65 of the M4Road Traffic Regulation Act 1984.

(3)The Secretary of State may issue or approve for the purposes of this section codes of practice giving practical guidance as to the matters mentioned in subsection (1); and—

(a)so far as an undertaker complies with such a code of practice he shall be taken to comply with that subsection; and

(b)a failure in any respect to comply with any such code is evidence of failure in that respect to comply with that subsection.

(4)An undertaker who fails to comply with subsection (1) or (2) commits an offence and is liable on summary conviction to a fine not exceeding [F49level 5] on the standard scale.

(5)If it appears to the street authority that an undertaker has failed to comply with subsection (1) or (2), they may take such steps as appear to them necessary and may recover from the undertaker the costs reasonably incurred by them in doing so.

(6)If a person without lawful authority or excuse—

(a)takes down, alters or removes any fence, barrier, traffic sign or light erected or placed in pursuance of subsection (1) or (2) above, or

(b)extinguishes a light so placed,

he commits an offence and is liable on summary conviction to a fine not exceeding [F50level 5] on the standard scale.

Textual Amendments

F49Words in s. 65(4) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

F50Words in s. 65(6) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

C2040S. 65(2)(5): functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 paras. 1(i), 2

Commencement Information

I5S. 65 wholly in force: s. 65(1)(2)(4)-(6) in force at 1.4.1993 see s. 170(1) and S.I. 1992/2984, art. 2(3), Sch. 3; s. 65(3) in force at 14.7.1992 by S.I. 1992/1686, art. 2, Sch.

Marginal Citations

66 Avoidance of unnecessary delay or obstruction.E+W

(1)An undertaker executing street works which involve—

(a)breaking up or opening the street, or any sewer, drain or tunnel under it, or

(b)tunnelling or boring under the street,

shall carry on and complete the works with all such dispatch as is reasonably practicable.

(2)An undertaker who fails to do so commits an offence and is liable on summary conviction to a fine not exceeding [F51level 5] on the standard scale.

(3)Where an undertaker executing any street works creates an obstruction in a street to a greater extent or for a longer period than is reasonably necessary, the street authority may by notice require him to take such reasonable steps as are specified in the notice to mitigate or discontinue the obstruction.

(4)If the undertaker fails to comply with such a notice within 24 hours of receiving it, or any longer period specified in the notice, the authority may take the necessary steps and recover from him the costs reasonably incurred by them in doing so.

Textual Amendments

F51Words in s. 66(2) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

C2125S. 66(3)(4): functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(j)

67 Qualifications of supervisors and operatives.E+W

(1)It is the duty of an undertaker executing street works involving—

(a)breaking up the street, or any sewer, drain or tunnel under it, or

(b)tunnelling or boring under the street,

to secure that, except in such cases as may be prescribed, the execution of the works is supervised by a person having a prescribed qualification as a supervisor.

(2)It is the duty of an undertaker executing street works involving—

(a)breaking up or opening the street, or any sewer, drain or tunnel under it, or

(b)tunnelling or boring under the street,

to secure that, except in such cases as may be prescribed, there is on site at all times when any such works are in progress at least one person having a prescribed qualification as a trained operative.

(3)An undertaker who fails to comply with his duty under subsection (1) or (2) commits an offence and is liable on summary conviction to a fine not exceeding [F52level 5] on the standard scale.

(4)Regulations made by the Secretary of State for the purposes of this section may include provision with respect to—

(a)the approval of bodies conferring qualifications (and the withdrawal of such approval), and

(b)the circumstances in which a qualification may be conferred.

Textual Amendments

F52Words in s. 67(3) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

68 Facilities to be afforded to street authority.E+W

(1)An undertaker executing street works shall afford the street authority reasonable facilities for ascertaining whether he is complying with his duties under this Part.

(2)An undertaker who fails to afford the street authority such facilities commits an offence in respect of each failure and is liable on summary conviction to a fine not exceeding [F53level 4] on the standard scale.

Textual Amendments

F53Words in s. 68(2) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

C2130S. 68 applied (with modifications) (11.11.1996) by S.I. 1996/2714, art. 4(2)(3)

S. 68 applied (27.8.1998) by S.I. 1998/1936, art. 4(3)

S. 68 applied (21.5.1997) by S.I. 1997/1266, art. 5(2)(3)

S. 68 applied (with modifications) (24.7.2001) by S.I. 2001/3627, art. 4(3)(4)

C2136S. 68 applied (with modifications) (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(4) (with arts. 3(5), 15(3))

C2137S. 68 applied (with modifications) (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(3)(4) (with art. 52)

C2151S. 68 applied (with modifications) (21.8.2013) by The Croxley Rail Link Order 2013 (S.I. 2013/1967), arts. 1, 4(1)(2)

C2160S. 68 applied (with modifications) (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(4) (with art. 31(2))

C2165S. 68 applied (with modifications) (31.12.2014) by The Hornsea One Offshore Wind Farm Order 2014 (S.I. 2014/3331), arts. 1, 7(1)(2) (with arts. 37, 38)

C2167S. 68 applied (with modifications) (21.4.2015) by The Network Rail (Ordsall Chord) Order 2015 (S.I. 2015/780), arts. 1, 4(2)(3) (with art. 36(2))

C2173S. 68 applied (with modifications) (7.9.2016) by The Hornsea Two Offshore Wind Farm Order 2016 (S.I. 2016/844), arts. 1(2), 10(2)(f) (with arts. 37, 38)

C2182S. 68 applied (with modifications) (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(4)(5) (with arts. 55-57, Sch. 8 para. 13)

C2188S. 68 applied (with modifications) (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(4)(5) (with arts. 55, 56)

C2196S. 68 applied (with modifications) (19.6.2020) by The Cleve Hill Solar Park Order 2020 (S.I. 2020/547), arts. 1, 9(2)(d)(h) (with art. 37)

C2210S. 68 applied (with modifications) (25.3.2022) by The Bridgwater Tidal Barrier Order 2022 (S.I. 2022/299), arts. 1, 3(4)(5) (with art. 55)

C2257S. 68 applied (25.2.2026) by The A46 Coventry Junctions (Walsgrave) Development Consent Order 2026 (S.I. 2026/125), arts. 1, 10(4)(5) (with arts. 40, 45, Sch. 9) (which affecting provisions were superseded by S.I. 2026/537, arts. 1, 10(4)(5) (with arts. 40, 45, Sch. 9))

C2263S. 68: functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(k)

69 Works likely to affect other apparatus in the street.E+W

(1)Where street works are likely to affect another person’s apparatus in the street, the undertaker executing the works shall take all reasonably practicable steps—

(a)to give the person to whom the apparatus belongs reasonable facilities for monitoring the execution of the works, and

(b)to comply with any requirement made by him which is reasonably necessary for the protection of the apparatus or for securing access to it.

(2)An undertaker who fails to comply with subsection (1) commits an offence in respect of each failure and is liable on summary conviction to a fine not exceeding [F54level 4] on the standard scale.

(3)In proceedings against a person for such an offence it is a defence for him to show that the failure was attributable—

(a)to his not knowing the position, or not knowing of the existence, of another person’s apparatus, or

(b)to his not knowing the identity or address of the person to whom any apparatus belongs,

and that his ignorance was not due to any negligence on his part or to any failure to make inquiries which he ought reasonably to have made.

Textual Amendments

F54Words in s. 69(2) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

C2264S. 69 excluded (27.11.1992) by S.I. 1992/2984, art. 8

C2266S. 69 applied (27.8.1998) by S.I. 1998/1936, art. 4(3)

S. 69 applied (21.5.1997) by S.I. 1997/1266, art. 5(2)(3)

S. 69 applied (11.11.1996) by S.I. 1996/2714, art. 4(2)(3)

S. 69 applied (13.1.1999) by S.I. 1998/3269, art. 4(2)(3)

S. 69 applied (10.2.1997) by S.I. 1997/264, art. 8(6)(7)

S. 69 applied (with modifications) (30.4.1999) by S.I. 1999/1306, art. 8(4)(5)

S. 69 applied (with modifications) (21.7.1999) by S.I. 1999/2129, art. 8(5)(6)

S. 69 applied (with modifications) (20.8.1999) by S.I. 1999/2336, art. 9(5)(6)(8)

S. 69 applied (with modifications) (23.8.1999) by S.I. 1999/2981, art. 7(5)(6)

S. 69 applied (4.4.1996) by S.I. 1996/937, art. 8(4)(5)

S. 69 applied (with modifications) (29.3.2001) by S.I. 2001/1348, art. 21(3)-(5)

S. 69 applied (with modifications) (29.3.2001) by S.I. 2001/1347, art. 3(3)

S. 69 applied (with modifications) (18.7.2001) by S.I. 2001/2870, art. 10(6)

S. 69 applied (with modifications) (24.7.2001) by S.I. 2001/3627, art. 4(3)(4)

S. 69 applied (with modifications) (9.11.2001) by S.I. 2001/3682, art. 8(6)

C2268S. 69 applied (with modifications) (28.4.2003) by The Network Rail (West Coast Main Line) Order 2003 (S.I. 2003/1075), arts. 1, 13(6)(7)(8) (with art. 40)

C2270S. 69 applied (with modifications) (19.11.2004) by The Scarweather Sands Offshore Wind Farm Order 2004 (S.I. 2004/3054), arts. 1, 6(4)(5) (with art. 38)

C2271S. 69 applied (with modifications) (11.2.2005) by The Merseytram (Liverpool City Centre to Kirkby) Order 2005 (S.I. 2005/120), arts. 1, 4(4)(5) (with arts. 65, 66)

C2276S. 69 applied (with modifications) (26.8.2005) by The River Tyne (Tunnels) Order 2005 (S.I. 2005/2222), arts. 1, 8(9)(10) (with arts. 45(1), 48, Sch. 10 paras. 21, 29)

C2277S. 69 applied (with modifications) (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(4) (with arts. 3(5), 15(3))

C2278S. 69 applied (with modifications) (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(3)(4) (with art. 52)

C2282S. 69 applied (with modifications) (13.12.2006) by The Network Rail (Thameslink 2000) Order 2006 (S.I. 2006/3117), arts. 1, 16(6)(7) (with arts. 34, 35(2))

C2283S. 69 applied (with modifications) (13.12.2006) by The Luton Dunstable Translink Order 2006 (S.I. 2006/3118), arts. 1, 10(5)(6)

C2284S. 69 applied (with modifications) (19.3.2007) by The Ouseburn Barrage Order 2007 (S.I. 2007/608), arts. 1, 8(2) (with arts. 46-48, Sch. 6 para. 23)

C2339S. 69 applied (with modifications) (21.8.2013) by The Croxley Rail Link Order 2013 (S.I. 2013/1967), arts. 1, 4(1)(2)

C2350S. 69 applied (with modifications) (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(4) (with art. 31(2))

C2356S. 69 applied (with modifications) (31.12.2014) by The Hornsea One Offshore Wind Farm Order 2014 (S.I. 2014/3331), arts. 1, 7(1)(2) (with arts. 37, 38)

C2373S. 69 applied (with modifications) (21.4.2015) by The Network Rail (Ordsall Chord) Order 2015 (S.I. 2015/780), arts. 1, 4(2)(3) (with art. 36(2))

C2381S. 69 applied (with modifications) (7.9.2016) by The Hornsea Two Offshore Wind Farm Order 2016 (S.I. 2016/844), arts. 1(2), 10(2)(g) (with arts. 37, 38)

C2390S. 69 applied (with modifcations) (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(4)(5) (with arts. 55-57, Sch. 8 para. 13)

C2396S. 69 applied (with modifications) (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(4)(5) (with arts. 55, 56)

C2403S. 69 applied (with modifications) (19.6.2020) by The Cleve Hill Solar Park Order 2020 (S.I. 2020/547), arts. 1, 9(2)(e)(h) (with art. 37)

C2417S. 69 applied (with modifications) (25.3.2022) by The Bridgwater Tidal Barrier Order 2022 (S.I. 2022/299), arts. 1, 3(4)(5) (with art. 55)

C2442S. 69 applied (9.2.2024) by The A12 Chelmsford to A120 Widening Development Consent Order 2024 (S.I. 2024/60), arts. 1, 12(4)(5) (with arts. 4, 52, Sch. 11 paras. 6, 24, 39(1), 55(1), 84)

ReinstatementE+W

70 Duty of undertaker to reinstate.E+W

(1)It is the duty of the undertaker by whom street works are executed to reinstate the street.

[F55(1A)The reinstatement required by subsection (1) may be permanent or interim.]

(2)He shall begin the reinstatement as soon after the completion of any part of the street works as is reasonably practicable and shall carry on and complete the reinstatement with all such dispatch as is reasonably practicable.

[F56(3)He shall within [F5710] working days from the date on which the reinstatement is completed give notice to the street authority of that completion—

(a)stating whether the reinstatement is permanent or interim; and

(b)giving such other information about the reinstatement as may be prescribed.

(4)If the reinstatement is interim, he shall complete the permanent reinstatement of the street as soon as reasonably practicable, and in any event within 6 months from the date on which the interim reinstatement was completed.

(4A)He shall, within [F5810] working days from the date on which the permanent reinstatement required by subsection (4) is completed, give notice to the street authority of that completion, giving such other information about the reinstatement as may be prescribed.

(4B)The Secretary of State may by regulations modify the period specified in subsection (3), (4) or (4A).]

(5)The permanent reinstatement of the street shall include, in particular, the reinstatement of features designed to assist people with a disability.

(6)An undertaker who fails to comply with any provision of this section commits an offence and is liable on summary conviction—

[F59(a)in the case of an offence consisting of a failure to comply with subsection (3) or (4A), to a fine not exceeding level 4 on the standard scale; and

(b)in any other case, to a fine not exceeding level 5 on that scale.]

(7)In proceedings against a person for an offence of failing to comply with subsection (2) it is a defence for him to show that any delay in reinstating the street was in order to avoid hindering the execution of other works, or other parts of the same works, to be undertaken immediately or shortly thereafter.

Textual Amendments

F55S. 70(1A) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 54(2), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 8); S.I. 2007/3174, art. 2, Sch. (with art. 9)

F56S. 70(3)-(4B) substituted for s. 70(3)(4) (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 54(3), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 8); S.I. 2007/3174, art. 2, Sch. (with art. 9)

F59S. 70(6)(a)(b) substituted for words in s. 70(6) (4.10.2004 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 40(3), 99(1); S.I. 2004/2380, art. 2(d)(ii) (with art. 3); S.I. 2007/1890, art. 2, Sch.; S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

C2470S. 70 excluded (27.11.1992) by S.I. 1992/2984, art. 9

Commencement Information

I6S. 70 wholly in force: s.70(1)-(3)(5)-(7) in force at 1.1.1993 see s. 170(1) and S.I. 1992/2984, art. 2(2), Sch. 2; s. 70(4) in force at 14.7.1992, see s. 170 and S.I. 1992/1686, art. 2, Sch.

71 Materials, workmanship and standard of reinstatement.E+W

(1)An undertaker executing street works shall in reinstating the street comply with such requirements as may be prescribed as to the specification of materials to be used and the standards of workmanship to be observed.

(2)He shall also ensure that the reinstatement conforms to such performance standards as may be prescribed—

(a)in the case of interim reinstatement, until permanent reinstatement is effected, and

(b)in the case of permanent reinstatement, for the prescribed period after the completion of the reinstatement.

This obligation is extended in certain cases and restricted in others by the provisions of section 73 as to cases where a reinstatement is affected by subsequent works.

(3)Regulations made for the purposes of this section may make different provision in relation to different classes of excavation and different descriptions of street, and in relation to interim and permanent reinstatement.

(4)The Secretary of State may issue or approve for the purposes of this section codes of practice giving practical guidance as to the matters mentioned in subsections (1) and (2); and regulations made for the purposes of this section may provide that—

(a)so far as an undertaker complies with such a code of practice he shall be taken to comply with his duties under this section; and

(b)a failure in any respect to comply with any such code is evidence of failure in that respect to comply with those duties.

(5)An undertaker who fails to comply with his duties under this section commits an offence and is liable on summary conviction to a fine not exceeding [F60level 5] on the standard scale.

Textual Amendments

F60Words in s. 71(5) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)

C595Ss. 54-106 applied (3.8.2024) by The Mallard Pass Solar Farm Order 2024 (S.I. 2024/796), arts. 1, 8(3) (with Sch. 15)

C597Ss. 54-106 applied (3.8.2024) by The Sunnica Energy Farm Order 2024 (S.I. 2024/802), arts. 1, 8(4) (with art. 44, Sch. 12)

C602Ss. 54-106 applied (15.2.2025) by The West Burton Solar Project Order 2025 (S.I. 2025/116), arts. 1, 8 (with art. 47, Sch. 15)

C613Ss. 54-106 applied (11.7.2025) by The Oaklands Farm Solar Park Order 2025 (S.I. 2025/739), arts. 1, 8(4) (with Sch. 10)

C620Ss. 54-106 applied (5.11.2025) by The Tillbridge Solar Order 2025 (S.I. 2025/1105), arts. 1, 8(3) (with art. 49, Sch. 15)

72 Powers of street authority in relation to reinstatement.E+W

(1)The street authority may carry out such investigatory works as appear to them to be necessary to ascertain whether an undertaker has complied with his duties under this Part with respect to reinstatement.

If such a failure is disclosed, the undertaker shall bear the cost of the investigatory works; if not, the street authority shall bear the cost of the investigatory works and of any necessary reinstatement.

(2)Where an undertaker has failed to comply with his duties under this Part with respect to reinstatement, he shall bear the cost of—

(a)a joint inspection with the street authority to determine the nature of the failure and what remedial works need to be undertaken,

(b)an inspection by the authority of the remedial works in progress, and

(c)an inspection by the authority when the remedial works have been completed.

(3)The street authority may by notice require an undertaker who has failed to comply with his duties under this Part with respect to reinstatement to carry out the necessary remedial works within such period of not less than 7 working days as may be specified in the notice.

If he fails to comply with the notice, the authority may carry out the necessary works and recover from him the costs reasonably incurred by them in doing so.

(4)If it appears to the street authority that a failure by an undertaker to comply with his duties under this Part as to reinstatement is causing danger to users of the street, the authority may carry out the necessary works without first giving notice and may recover from him the costs reasonably incurred by them in doing so.

They shall, however, give notice to him as soon as reasonably practicable stating their reasons for taking immediate action.

Modifications etc. (not altering text)

C430Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C498Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C506Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C540Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C569Ss. 54-106 applied (with modifications) (4.11.2022) by The A47/A11 Thickthorn Junction Development Consent Order 2022 (S.I. 2022/1070), arts. 1, 15(3) (with arts. 4, 52, Sch. 9 para. 82)

C579Ss. 54-106 applied (18.7.2023) by The Longfield Solar Farm Order 2023 (S.I. 2023/734), arts. 1, 8(3)