Search Legislation

The Great Yarmouth Outer Harbour Revision Order 2005

What Version

 Help about what version
  • Latest available (Revised)
  • Original (As made)

Status:

This is the original version (as it was originally made). This item of legislation is currently only available in its original format.

Citation and commencement

1.—(1) This Order may be cited as the Great Yarmouth Outer Harbour Revision Order 2005 and shall come into force on 6th October 2005.

(2) The Great Yarmouth Port Authority Acts and Orders 1866 to 1990, the Great Yarmouth Outer Harbour Act 1986 (Extension of time) Order 1991 and this Order may be cited together as the Great Yarmouth Port Authority Acts and Orders 1866 to 2005.

Interpretation

2.  In this Order—

“the 1986 Act” means the Great Yarmouth Outer Harbour Act 1986(1);

“the annexed map” means the map contained in the Schedule to this Order;

the Authority” means the Great Yarmouth Port Authority;

“the esplanade” means so much of the way known as the Esplanade as lies between the points marked X (National Grid reference point TG 53185 E 05505 N) and Y (National Grid reference point TG 53370 E 03810 N) on the annexed map; and

“the works” means the works authorised by Part II (Works, etc.) of the 1986 Act.

Planning permission for Outer Harbour works

3.—(1) Section 44 (Planning permission) of the 1986 Act shall have effect subject to the modification that in subsection (2), for the words “within 10 years after the passing of this Act” there are substituted the words “before 8th November 2010”.

Power to stop up esplanade

4.—(1) Subject to paragraph (2) below the Authority may, in connection with the construction of the works, permanently stop up and discontinue the esplanade.

(2) The Authority shall not exercise the powers of paragraph (1) above until it is ready to commence construction of so much of the works as requires the closure of the esplanade.

(3) Upon the permanent stopping up of the esplanade pursuant to paragraph (1) above, any public rights of way which is a footpath or bridleway over or along the esplanade shall be extinguished.

Protection for Great Yarmouth Borough Council and Waveney District Council

5.  For section 33 (For protection of Great Yarmouth Borough Council and Waveney District Council) of the 1986 Act there shall be substituted the following:

33.  The following provisions shall, unless otherwise agreed in writing between the Great Yarmouth Borough Council and the Waveney District Council, or either of them, and the Authority have effect:—

(1) In this section—

“accumulation” means any accumulation of silt or other material in the protected areas;

“construction” includes execution and placing, maintenance, extension, enlargement, alteration, replacement, relaying and removal; and “construct” and “constructed” have corresponding meanings;

“the council” means—

(a)

In relation to the Borough of Great Yarmouth, and to the protected areas in the Borough, the Great Yarmouth Borough Council;

(b)

in relation to the District of Waveney, and to the protected areas in the District, the Waveney District Council;

“damage” means any adverse effects to the protected areas;

“the district” means the Borough of Great Yarmouth or the District of Waveney, as the case may require;

“erosion” means any erosion of the protected areas;

“the protected areas” means the beaches, sea walls, promenades, groynes, revetments and any other coast protection structures in the district;

“specified work” means any permanent or temporary work or operation authorised by this Act (which includes for the avoidance of doubt, any dredging and any exploratory geotechnical investigations that may be undertaken).

(2) If, during the construction of a specified work or within 10 years after the completion of such work and wholly or partly in consequence of its construction there is caused or created an accumulation or erosion or alteration of the tidal flow or littoral drift which causes damage, or reasonable expectation of damage, the Authority, if so required by the council before or within the period of 10 years after such completion shall remedy such accumulation, erosion, alteration of tidal flow or littoral drift, in the manner specified in subsection (4) below and, if it refuses or fails so to do, the council may itself cause work to be done and may recover the reasonable cost thereof from the Authority.

(3) Should any accumulation or erosion or alteration of the tidal flow or littoral drift which causes damage or reasonable expectation of damage, arise in consequence of such construction within the said period of 10 years and be remedied in accordance with subsection (2) above, any recurrence of such accumulation or erosion or alteration of the tidal flow or littoral drift shall from time to time be so remedied by the Authority during the said period of 10 years and at any time thereafter, save that the Authority’s obligations under this paragraph shall cease in the event that following the remedying of any accumulation or erosion or alteration of the tidal flow or littoral drift a period of 10 years elapses without any further accumulation or erosion or alteration of the tidal flow or littoral drift being caused or created in consequence of such construction.

(4) For the purposes of subsections (2) and (3) above—

(a)in the case of an accumulation, the remedy shall be its removal; and

(b)in the case of erosion or alteration of tidal flow or littoral drift, the remedy shall be the carrying out of such reconstruction works and other protective works or measures as may be reasonably required by the council:

Provided that in the event that surveys, inspections, tests or sampling establish that such accumulation or erosion or alteration of tidal flow or littoral drift would have been caused in any event by factors other than the construction of a specified work the Authority shall be liable to remedy such accumulation or erosion or alteration of tidal flow or littoral drift only to the extent that the same is attributable to such construction.

(5) For the purposes of subsection (2) above the date of completion of a work shall be the date on which it is brought into use.

(6) Any difference arising between the Authority and the council under this section (other than a difference as to its meaning or construction) shall be determined by arbitration..

Protection for Environment Agency

6.—(1) The following provisions shall, unless otherwise agreed in writing between the Environment Agency (in this article referred to as “the Agency”) and the Authority, have effect.

(2) In this article—

“accumulation” means any accumulation of silt or other material;

“construction” includes execution and placing, maintenance, extension, enlargement, alteration, replacement, relaying and removal; and “construct” and “constructed” have corresponding meanings;

“drainage work” means any watercourse and any land used for providing flood storage capacity for any watercourse and any bank, wall, embankment, outfall or other structure or appliance constructed or used for land drainage, defence against water (including sea water) or tidal monitoring;

“erosion” means any erosion of the bed or shore of the sea or of the bed or banks of the river Yare;

“the fishery” means fish in, or migrating to or from, any river and the spawn, habitat or food of such fish;

“outfall” means—

(a)

any existing land drainage outfall for which the Agency is responsible; or

(b)

any sewer, pipe or drain provided for groundwater, surface water or storm overflow sewerage;

“plans” includes sections, descriptions, drawings, specifications and method statements and other such particulars;

“specified work” means any permanent or temporary work or operation authorised by the 1986 Act (which includes for the avoidance of doubt, any dredging and any exploratory geotechnical investigations that may be undertaken); and

“watercourse” has the meaning given in section 221(1) of the Water Resources Act 1991(2).

(3) (a) Before beginning to construct any specified work, the Authority shall submit to the Agency plans of the work and such further particulars available to it as the Agency may reasonably require.

(b)Without prejudice to sub-paragraph (a) above, the Authority shall ensure that its contractor shall provide the Agency with all necessary hydraulic information in order to identify and quantify any effects of accumulation or erosion or alteration of the tidal flow or littoral drift which are likely to be caused by any such specified work and such information shall be accompanied by an appropriate assessment of that information and of any remedial measures which may be reasonably necessary having regard to any such likely effects.

(c)Any such specified work shall not be constructed except in accordance with such plans as may be approved in writing by the Agency or as settled in accordance with paragraph (17) below.

(d)Any approval of the Agency required under this paragraph—

(i)shall not be unreasonably withheld;

(ii)shall be deemed to have been given if it is neither given nor refused in writing and, in the case of a refusal, with a statement of the grounds for refusal within two months of the submission of plans for approval;

(iii)may be given subject to such reasonable requirements as the Agency may impose for the protection of any drainage work or fishery or water resources, for the prevention of flooding and water pollution and in the discharge of its environmental and recreational duties.

(4) Without prejudice to the generality of paragraph (3) above, the requirements which the Agency may impose under that paragraph include—

(a)conditions as to the time at which and the manner in which any work is to be carried out;

(b)conditions requiring the Authority at its own expense—

(i)to provide or maintain means of access for the Agency;

(ii)to construct such protective works whether temporary or permanent during the construction of the specified works (including the provision of flood banks, walls or embankments, outfalls and other new works and the strengthening, repair or renewal of existing banks, walls or embankments, outfalls or other works) as are reasonably necessary to safeguard any drainage work against damage or to secure that its efficiency for flood defence purposes is not impaired and that the risk of flooding is not otherwise increased by reason of any specified work;

(iii)to monitor accumulation, erosion or alterations of the tidal flow or littoral drift arising during the construction or following the completion of the specified works;

(iv)to provide, maintain and operate arrangements for dealing with any pollution incidents which may occur during and as a result of the construction of the specified works.

(5) Any specified work, and all protective works required by the Agency under paragraph (4) above, shall be constructed to the reasonable satisfaction of the Agency and the Agency shall be entitled by its officer to watch and inspect the construction of such works.

(6) The Authority shall give to the Agency notice in writing of the commencement of any specified work not less than 14 days prior to its commencement and notice in writing of its completion not later than 7 days after such completion.

(7) (a) If, during the construction of a specified work or within 10 years after the completion of such work and wholly or partly in consequence of its construction there is caused or created an accumulation or erosion or alteration of the tidal flow or littoral drift which causes damage, or reasonable expectation of damage, the Authority, if so required by the Agency before or within the period of 10 years after such completion, shall remedy such accumulation, erosion, alteration of tidal flow or littoral drift, in the manner specified in sub-paragraph (d) below and, if it refuses or fail so to do, the Agency may itself cause work to be done and may recover the reasonable cost thereof from the Authority.

(b)Should any accumulation or erosion or alteration of the tidal flow or littoral drift which causes damage or reasonable expectation of damage, arise in consequence of such construction within the said period of 10 years and be remedied in accordance with sub-paragraph (a) above, any recurrence of such accumulation or erosion or alteration of the tidal flow or littoral drift shall from time to time be so remedied by the Authority during the said period of 10 years and at any time thereafter, save that the Authority’s obligation under this paragraph shall cease in the event that following the remedying of any accumulation or erosion or alteration of the tidal flow or littoral drift a period of 10 years elapses without any further accumulation or erosion or alteration of the tidal flow or littoral drift being caused or created in consequence of such construction.

(c)In sub-paragraphs (a) and (b) above, “damage” means any damage to the bed or banks of the river Yare or any adverse effect upon the structure or operation of any outfall, flood or sea defences or any jetty or other structure under the jurisdiction of the Agency for the purposes of the Water Resources Act 1991.

(d)For the purposes of sub-paragraphs (a) and (b) above—

(i)in the case of an accumulation, the remedy shall be its removal or such other protective works or measures as may be reasonably required by the Agency; and

(ii)in the case of erosion or alteration of tidal flow or littoral drift, the remedy shall be the carrying out of such reconstruction works and other protective works or measures as may be reasonably required by the Agency.

(e)In the event that surveys, inspections, tests or sampling establish that such accumulation or erosion or alteration of tidal flow or littoral drift would have been caused in any event by factors other than the construction of a specified work the Authority shall be liable to remedy such accumulation or erosion or alteration of tidal flow or littoral drift only to the extent that the same is attributable to such construction.

(8) For the purposes of paragraphs (6) and (7)(a) above the date of completion of a work shall be the date on which it is brought into use.

(9) (a) Any specified work which provides a defence against flooding shall be maintained by and at the expense of the Authority to the reasonable satisfaction of the Agency.

(b)If any such work is no longer required by the Authority or is not maintained to the reasonable satisfaction of the Agency, the Agency may by notice in writing require the Authority at the Authority’s own expense to repair and restore the work, or any part thereof, or to remove the work and restore the site (including any sea defences) to its former condition, to such an extent and within such limits as the Agency thinks proper.

(c)If, on the expiration of 30 days from the date on which a notice is served upon the Authority it has failed to comply with the requirements of the notice, the Agency may execute the works specified in the notice, and any expenditure incurred by it in so doing shall be recoverable from the Authority.

(10) If, by reason of the construction of any specified work or by reason of the failure of that work or of the Authority to maintain it, the efficiency of any drainage work for flood defence purposes is impaired or that work is damaged, such impairment or damage shall be made good by the Authority to the reasonable satisfaction of the Agency and, if the Authority fails to do so, the Agency may make good the same and recover from the Authority the expense reasonably incurred by it in so doing.

(11) If any works are constructed by the Agency in relation to a drainage work the Authority shall have no claim against the Agency in respect of any additional costs which may be incurred by the Authority as a result of such works.

(12) The Authority shall indemnify the Agency in respect of all reasonable costs, charges and expenses which the Agency may reasonably incur or have to pay or which it may sustain—

(a)in the examination or approval of plans under this article;

(b)in the inspection of the construction of the specified works or any protective works required by the Agency under this article.

(13) (a) Without prejudice to the other provisions of this article the Authority shall indemnify the Agency from all claims, demands, proceedings, costs, damages or expenses or loss which may be made or taken against, or recovered from or incurred by, the Agency by reason of the construction of any of the works or by reason of their maintenance, repair, alteration, renewal, removal, existence or use or any act or omission of the Authority, its contractors, agents, workmen, or servants whilst engaged upon any such work.

(b)The Agency shall give to the Authority reasonable notice of any such claim or demand and no settlement or compromise thereof shall be made without the agreement of the Authority which agreement shall not be unreasonably withheld.

(14) The fact that any work or thing has been executed or done in accordance with a plan approved or deemed to be approved by the Agency, or to its satisfaction, or in accordance with any directions or award of an arbitrator, shall not (if it was done without neglect or default on behalf of the Agency, of any person in its employ or of its contractors or agents) relieve the Authority from any liability under the provisions of this article.

(15) Except as otherwise provided by this article, nothing in this Order or the 1986 Act shall prejudice or affect in their application to the Agency the powers, rights, jurisdiction and obligations conferred, arising or imposed under the Land Drainage Act 1991(3), the Salmon and Freshwater Fisheries Act 1975(4), the Water Resources Act 1991 or any other enactment, byelaw or regulation relating to the Agency.

(16) For the purposes of section 109 of the Water Resources Act 1991 (as to structures in, over or under watercourses) as applying to the construction of any specified work, any approval given or deemed to be given by the Agency under this article with respect to such construction shall be deemed to constitute a consent under that section.

(17) (a) Unless the parties agree to arbitration any difference arising between the Authority and the Agency under paragraph (3) above shall be settled by the Secretary of State for the Environment, Food and Rural Affairs on a reference to her by either party after notice in writing to the other.

(b)Subject to sub-paragraph (a) above, any difference arising between the Authority and the Agency under this article (other than a difference as to its meaning or construction) shall be referred to and settled by a single arbitrator appointed by agreement between the parties on reference to him by either party, after notice in writing to the other, or, in default of agreement, by the President of the Institution of Civil Engineers.

Protection for Associated British Ports

7.—(1) The following provisions of this article shall, unless otherwise agreed in writing between Associated British Ports (in this article referred to as “ABP”) and the Authority, have effect.

(2) In this article—

“accumulation” means any accumulation of silt or other material in the protected areas;

“construction” includes execution and placing, maintenance, extension, enlargement, alteration, replacement, relaying and removal; and “construct” and “constructed” have corresponding meanings;

“damage” means any obstruction or danger to navigation within the protected areas, or any adverse effects to any works owned by, or under the management or control of, ABP within the protected areas, or any detrimental effects on the operation of the protected areas, or on the fulfilment of ABP’s duties in connection with the protected areas;

“erosion” means any erosion of the bed of the sea or of any lands within the protected areas;

“the protected areas” means the port of ABP at Lowestoft and the seaward approaches thereto from time to time; and

“specified work” means any permanent or temporary work or operation authorised by the 1986 Act (which includes for the avoidance of doubt, any dredging and any exploratory geotechnical investigations that may be undertaken).

(3) If, during or after the construction of a specified work, and wholly or partly in consequence of its construction there is caused or created an accumulation or erosion or alteration of the tidal flow or littoral drift which causes damage, or reasonable expectation of damage, the Authority, if so required by ABP shall remedy such accumulation, erosion, alteration of tidal flow or littoral drift, in the manner specified in paragraph (4) below and, if it refuses or fails so to do, ABP may itself cause work to be done and, provided that ABP has notified the Authority in writing of its intention to cause such work to be done prior to carrying out such work and has acted reasonably in concluding that it should do such work, ABP may recover the reasonable cost thereof from the Authority.

(4) For the purposes of this article—

(a)in the case of an accumulation, the remedy shall be its removal; and/or such other protective works or measures as may be reasonably required by ABP; and

(b)in the case of erosion or alteration of tidal flow or littoral drift, the remedy shall be the carrying out of such reconstruction works and/or such other protective works or measures as may be reasonably required by ABP.

(5) If the Authority establishes by surveys, inspections, tests or sampling, and without unreasonably delaying the execution of any remedial action required under paragraph (3) above, that such accumulation or erosion or alteration of tidal flow or littoral drift would have been caused in any event by factors other than the construction of a specified work the Authority shall be liable to remedy such accumulation or erosion or alteration of tidal flow or littoral drift only to the extent that the same is attributable to such construction.

(6) The Authority’s obligations pursuant to paragraphs (3) to (5) above shall commence upon the commencement of the construction of a specified work and terminate at the end of the first continuous period of ten years commencing after completion of the specified works during which no remedial work is required pursuant to this article.

(7) For the purposes of paragraph (6) above the date of completion of a work shall be the date on which it is brought into use.

(8) Any difference arising between the Authority and ABP under this article (other than a difference as to its meaning or construction) shall be determined by arbitration in the manner provided by the 1986 Act.

Signed by authority of the Secretary of State for Transport

Phil Carey

Head of Ports Division,

Department for Transport

14 September 2005

Back to top

Options/Help

Print Options

Close

Legislation is available in different versions:

Latest Available (revised):The latest available updated version of the legislation incorporating changes made by subsequent legislation and applied by our editorial team. Changes we have not yet applied to the text, can be found in the ‘Changes to Legislation’ area.

Original (As Enacted or Made):The original version of the legislation as it stood when it was enacted or made. No changes have been applied to the text.

Close

Opening Options

Different options to open legislation in order to view more content on screen at once

Close

More Resources

Access essential accompanying documents and information for this legislation item from this tab. Dependent on the legislation item being viewed this may include:

  • the original print PDF of the as enacted version that was used for the print copy
  • lists of changes made by and/or affecting this legislation item
  • confers power and blanket amendment details
  • all formats of all associated documents
  • correction slips
  • links to related legislation and further information resources
Close

More Resources

Use this menu to access essential accompanying documents and information for this legislation item. Dependent on the legislation item being viewed this may include:

  • the original print PDF of the as made version that was used for the print copy
  • correction slips

Click 'View More' or select 'More Resources' tab for additional information including:

  • lists of changes made by and/or affecting this legislation item
  • confers power and blanket amendment details
  • all formats of all associated documents
  • links to related legislation and further information resources